Justia Contracts Opinion Summaries

This appeal involved Empire Fire and Marine Insurance Company's obligations under an "Insurance for Non-Trucking Use" policy issued to Drielick Trucking. The policy contained a business-use exclusion, which included two clauses that Empire argued precluded coverage in this case. The Court of Appeals agreed that the first clause precluded coverage when the covered vehicle was not carrying property at the time of the accident, was in this case. Thus, the Court of Appeals expressly declined to address the second clause relating to leased covered vehicles. The Supreme Court held that the Court of Appeals erred in its interpretation of the first clause. The case to the trial court for further fact-finding to determine whether Drielick Trucking and Great Lakes Carriers Corporation (GLC) entered into a leasing agreement for the use of Drielick Trucking’s semi-tractors as was contemplated under the policy's clause related to a leased covered vehicle. View "Estate of Eugene Hunt v. Drielick" on Justia Law

In January 2006, two former payday lenders, defendants B&B Investment Group, Inc., and American Cash Loans, LLC, began to market and originate high-cost signature of $50 to $300, primarily to less-educated and financially unsophisticated individuals. The loans were for twelve months, payable biweekly, and carried annual percentage rates ranging from 1,147.14 to 1,500%. The Attorney General’s Office sued Defendants, alleging that the loan products were procedurally and substantively unconscionable under the common law and that they violated the Unfair Practices Act (UPA). The district court found that Defendants’ marketing and loan origination procedures were unconscionable and enjoined certain of its practices in the future, but declined to find the high-cost loans substantively unconscionable, concluding that it is the Legislature’s responsibility to determine limits on interest rates. Both parties appealed. Upon review, the Supreme Court affirmed the district court’s finding of procedural unconscionability. However, the Court reversed the district court’s refusal to find that the loans were substantively unconscionable because under the UPA, courts have the responsibility to determine whether a contract results in a gross disparity between the value received by a person and the price paid. The Supreme Court concluded that the interest rates in this case were substantively unconscionable and violated the UPA. View "New Mexico ex rel. King v. B&B Investment Group, Inc." on Justia Law

Appellants filed a class action complaint alleging that the circuit court clerk falsely and fraudulently notarized oil-and-gas leases outside the presence of the landowners. The complaint requested an injunction and other relief. After a hearing, the circuit court sua sponte dismissed the case for lack of damages. The Supreme Court reversed, holding that the circuit court improperly dismissed Appellants’ complaint, as the sua sponte dismissal foreclosed the possibility that Appellants might have been able to submit additional evidence indicating that there remained a genuine issue of material fact, i.e., that they had suffered damages. View "Lipsey v. Giles" on Justia Law

The Club is a non-profit provider of protection and indemnity insurance. The Club's Rules include a choice-of-law provision selecting New York law and a two-year statute of limitations for claims against the Club. The Club filed a civil action against defendant alleging that it breached the insurance contract by failing to reimburse the Club for a shortfall and by failing to pay the overdue insurance premiums. The court agreed with the district court, and precedent, that an otherwise valid choice-of-law provision in a maritime contract is enforceable and may require application of a jurisdiction's statute of limitations, in lieu of the doctrine of laches, to govern issues regarding the timeliness of claims asserted under that agreement. Accordingly, the court held that the district court correctly applied New York's six-year statute of limitations to the Club's claims arising under its maritime insurance contract with plaintiff. Therefore, the court affirmed the judgment of the district court. View "American Steamship Owners v. Dann Ocean Towing, Inc." on Justia Law

Mark Hansen was a former vice president of Wilcox Industries Corp. After Hansen left Wilcox, he founded his own company, Advanced Life Support Technologies. Wilcox filed a complaint against Hansen, alleging that Hansen stole Wilcox’s customers and spread false and damaging information about Wilcox’s products. Hansen tendered his defense to Wilcox’s insurer, Sentry Insurance Company. Sentry denied coverage, stating that it did not have a duty to defend or indemnify Hansen against Wilcox’s claims. Hansen subsequently filed suit seeking a declaration that Sentry owed a duty to defend and indemnify him with respect to Wilson’s complaint. The district court granted summary judgment for Wilcox, concluding that Hansen did not qualify as an “insured” under Wilcox’s policy. The First Circuit affirmed, holding (1) Sentry owed no duty to defend or indemnify Hansen in the underlying litigation; and (2) there was no evidence in the record that would permit a reasonable jury to find that Sentry breached any contract with Hansen. View "Hansen v. Sentry Ins. Co." on Justia Law

In 2001, ASC and Paragon entered into a contract to develop and support computer software for the Chicago Tribune. This software, called the “Single Copy Distribution System” (SCDS) would allow the Tribune to manage and track newspaper deliveries and subscriptions. Tensions emerged and Paragon terminated the contract in 2003. ASC successfully sued Paragon in Ohio state court, obtaining a declaration that ASC was the sole owner of the SCDS. In federal court, ASC alleged copyright infringement, trademark infringement, breach of contract, conversion, tortious interference with a business relationship, unjust enrichment, and unfair competition based on Paragon’s alleged copying of the SCDS software to use in its DRACI software, developed in 2004 for another newspaper. After eight years of litigation, the district court granted summary judgment to Paragon on all claims. The Sixth Circuit affirmed, stating that ASC had never submitted any evidence identifying the unique protectable elements of SCDS, and that there was insufficient evidence to generate even an implication that DRACI is substantially similar to SCDS. View "Automated Solutions Corp. v. Paragon Data Sys., Inc." on Justia Law

Giuffre, an authorized dealer of Hyundai automobiles under a contract with that company's domestic affiliate (HMA), filed suit against HMA seeking to enjoin termination of the contract. HMA terminated its contract with Giuffre after a state court concluded that the dealer had engaged in fraudulent, illegal, and deceptive business practices - a clear breach of the contract terms. The district court granted summary judgment in favor of HMA, concluding that the breach was incurable and that HMA was entitled to terminate the contract immediately, notwithstanding the terms of section 463 of the New York Vehicle and Traffic Law. The court affirmed, concluding that section 463 did not abrogate the common law with respect to incurable breaches of contract. View "Giuffre Hyundai, Ltd. v. Hyundai Motor America, Inc." on Justia Law

Defendants Citation Oil & Gas Corp., Petro-Hunt LLC, and other working interest owners appealed a district court summary judgment quieting title to an oil and gas lease in Greggory Tank. In 1982, George and Phyllis Tank executed an oil and gas lease in favor of Petro-Lewis Funds, Inc. The parties agreed to extend the primary term of the lease for three more years, ending July 15, 1989. In May 1983, the Tank 3-10 well was spudded in the northwest quarter. The well produced until October 1996. In June 1998, the Tank 3-10R well was spudded and replaced the Tank 3-10 well. The Tank 3-10R well continues to produce oil or gas. In June 1988, the Tank 13-10 well was spudded in the southwest quarter. The well continuously produced oil or gas until October 2008, and intermittently produced oil or gas until January 2012. Tank was the successor in interest to George and Phyllis Tank and was the owner of minerals in the southwest quarter of section 10. In September 2011, Tank sued the defendants, seeking to cancel the oil and gas lease to the extent it covered the southwest quarter. The defendants moved for summary judgment, seeking dismissal of all of Tank's claims. The defendants argued the continued drilling and operation of oil and gas wells on the leased property maintained the lease beyond the primary term and the lease remained in full force and effect. The district court denied the defendants' motion for summary judgment, ruling the lease had expired and was no longer valid on the southwest quarter. The court determined summary judgment was appropriate because there were only issues of law to resolve, including the interpretation of an unambiguous contract and the application of undisputed facts. Finding no reversible error in the district court's decision, the Supreme Court affirmed. View "Tank v. Citation Oil & Gas Corp." on Justia Law

American General Contractors, Inc. ("AGC"), appealed a judgment assessing liability and awarding damages and interest for the cost of delays in the construction of the Williams County Law Enforcement Center in Williston. C&C Plumbing and Heating, LLP ("C&C"), the successful bidder for the mechanical prime contract, filed suit when construction the center was delayed approximately two years after "substantial completion" was supposed to have happened. The district court concluded it was appropriate for the County and AGC to share responsibility for providing temporary shelter and heat on the project. The court apportioned 47 percent of the liability for the costs of the delay for the three and one-half months of active interference to the County and 53 percent to AGC, for the four months delay inherent to the industry. The court awarded C&C approximately $73,000 on its claim against the County. After offsetting amounts owed between the parties, the court awarded AGC approximately $424,000 on its claim against the County. The court awarded Davis Masonry approximately $96,000 from AGC for masonry work completed under its subcontract with AGC, and rejected AGC's claimed offsets to that amount. Davis had provided heat, cover and shelter for the project during cold weather and sought $649,000 from the County and AGC for that expense including prompt payment interest. Davis had settled with the County for $530,000, and the court ruled AGC was responsible for 53 percent of the remaining $119,000, or $63,070. AGC argues the district court erred in determining AGC was liable for any of the costs incurred from the delay under its contract with the County. Finding no reversible error, the Supreme Court affirmed the district court. View "C&C Plumbing and Heating, LLP v. Williams County" on Justia Law

Patrick O’Basuyi filed suit against several defendants (collectively, “TriStar”) for breach of contract, quantum meruit and fraudulent conveyance. TriStar responded by filing a counterclaim for malicious prosecution. O’Basuyi filed a motion for separate trial of TriStar’s counterclaims. The trial court overruled the motion for separate trial, determining that Mo. R. Civ. P. 55.06, which governs joinder of claims, authorized its denial of O’Basuyi’s motion for separate trial of the malicious prosecution claim. O’Basuyi subsequently sought a writ of prohibition. The Supreme Court granted the request writ, holding (1) Rule 55.06 does not permit either joinder or trial of a malicious prosecution counterclaim with the underlying claim; and (2) therefore, the trial court erred in permitting the joint trial of the defendants’ counterclaim and O’Basuyi’s claims. View "State ex rel. O'Basuyi v. Hon. David Lee Vincent III" on Justia Law