Justia Contracts Opinion Summaries

The companies obtained an oil and gas lease from the government for a 5760-acre tract on the Outer Continental Shelf. They made an initial bonus payment of $23,236,314 and have paid additional rental payments of $54,720 per year. The lease became effective on August 1, 2008, and had an initial term running through July 31, 2016. It provided that it issued pursuant to and was subject to the Outer Continental Shelf Lands Act of August 7, 1953, (OCSLA) 43 U.S.C. 1331 and “all regulations issued pursuant to the statute in the future which provide for the prevention of waste and conservation of the natural resources of the Outer Continental Shelf and the protection of correlative rights therein; and all other applicable statutes and regulations.” In 2010, an explosion and fire on the Deepwater Horizon semi-submersible oil drilling rig in the Gulf of Mexico killed 11 workers and caused an oil spill that lasted several months. As a result, the government imposed new regulatory requirements, Oil Pollution Act (OPA), 33 U.S.C. 2701. The companies sued for breach of contract. The Claims Court and Federal Circuit ruled in favor of the government, finding that the government made the changes pursuant to OCSLA, not OPA. View "Century Exploration New Orleans, LLC v. United States" on Justia Law

In 2002 oil companies filed breach of contract actions against the government, concerning sales of offshore oil and glass leases in the 1980s. The Claims Court held that the government had breached its contracts by preventing the companies from drilling for oil in the offshore areas covered by the leases. The Federal Circuit affirmed the judgment and restitution awards of approximately $1 billion. Nycal, which held a 4.25 percent interest in two of the leases, waived its right to restitution and pursued a claim for lost profits. The Claims Court held that it was permissible for Nycal to seek lost-profits damages even though the other owners of the leases in which Nycal held a partial share had accepted restitution, but concluded that Nycal had not proved its case for lost profits. The Federal Circuit affirmed, noting the government’s evidence that Nycal could not have made a profit on its share of the leases.View "NYCAL Offshore Dev. Corp. v. United States" on Justia Law

In 2002, the Navy awarded Metcalf a contract to design and build 212 housing units in Hawaii by October, 2006, for $50 million. Problems arose involving soil conditions. The request for proposals stated that the “soil reconnaissance report” was “for preliminary information only” and required that the contractor conduct independent soil investigation, incorporating 48 C.F.R. 52.236-2, concerning site conditions that differ materially from those disclosed. Discussions delayed construction for a year. Metcalf implemented its preferred changes by over-excavating and using non-expansive fill, without a contract modification. The Navy denied that there was any material difference between pre-bid and post-award soil assessments, but approved some modifications. Metcalf was about 200 days behind schedule and began using “post-tension” concrete, which was more expensive but avoided the additional time and cost of over-excavation. The Navy amended the contract to approve use of post-tension concrete slabs. Metcalf claims additional delays resulting from the presence of more of a chemical contaminant than was expected. With respect to contamination, the Navy granted a 286-day extension and reimbursed $1,493,103. The Navy accepted the buildings in March, 2007. Metcalf alleged that its final cost was $76 million. The government paid less than $50 million. The Claims Court ruled in favor of the government, under the Contract Disputes Act, 41 U.S.C. 7104. The Federal Circuit vacated, holding that the court misconstrued what Metcalf needed to show to prove that the government breached its duty of good faith and fair dealing and misinterpreted certain contractual provisions.View "Metcalf Const. Co., LLC v. United States" on Justia Law

Crewzers was awarded blanket purchase agreements (BPAs) with the Forest Service to provide buses that transport fire crews to wildfires and other disaster areas in regional and national wilderness zones and to provide flame retardant tents to disaster areas. Both BPAs established dispatch priority lists within geographic zones. When an emergency arose, the Service would to submit an order for the highest-ranked (lowest-priced) resource available on the priority. BPAs are frameworks for future contracts and state that “If a Contractor cannot be reached or is not able to meet the time and date needed, the dispatcher may proceed with contacting the next resource on the dispatch priority list.” The Service has discretion to deviate from priority lists as needed and did not make any guarantee that it would actually place orders under the BPAs. The BPAs required Crewzers to accept orders only if “willing and able.” The Service terminated the Crewzers BPA for buses after Crewzers allegedly responded with unauthorized vehicles and attempted to bill at a higher-than-authorized rate and later terminated its BPA for tents after Crewzers allegedly provided tents that did not meet specifications or failed to deliver on time. Crewzers sought a declaratory judgment that it was entitled to damages or to reinstatement of the BPAs. The Claims Court dismissed. The Federal Circuit affirmed, finding that the BPAs were not binding contracts for purposes of invoking Tucker Act (28 U.S.C. 1491(a)) jurisdiction. View "Crewzers Fire Crew Transp., Inc. v. United States" on Justia Law

In 2001 KBR agreed to provide the Army with logistics support services during Operation Iraqi Freedom. Individual task orders required KBR to install, operate and maintain dining services near Mosul, Iraq on a cost-plus-award-fee basis. KBR selected ABC, a subcontractor, to build a prefabricated metal dining facility and to provide dining services for a camp population of 2,573. In June 2004, the Army ordered KBR to stop construction of the metal facility and begin construction of a reinforced concrete facility for an estimated 2,573 to 6,200+ persons. Instead of requesting bids for the new work, KBR kept ABC as the subcontractor due to the urgency of the request. ABC submitted a new proposal with a total monthly cost about triple the monthly cost initially quoted. ABC attributed the increased costs to additional labor and equipment to serve a larger population and to a drastic increase in the cost of labor and a severe shortage of staff willing to work in Iraq. Due to a calculation error, it was determined that ABC’s proposal was reasonable. KBR’s management reviewed and approved a change order, embodying ABC’s proposal. In 2005 the subcontract ended and title to the dining facility passed to the Army. In 2007, the Defense Contract Auditing Agency suspended payment of certain costs paid by KBR to ABC pursuant to the change order. KBR prepared a new price justification for the concrete dining facility and ultimately filed suit, seeking recovery of the $12,529,504 in costs disapproved for reimbursement. The Claims Court awarded $6,779,762. The Federal Circuit affirmed.View "Kellogg Brown & Root Servs. v. United States" on Justia Law

In 2006, the Federal Bureau of Prisons issued a Request for Proposals for the “design-build” construction of a federal correctional institution. The project involved a “cut-to-fill” site, meaning that the ground had to be leveled by excavating materials from one area of the site and using those materials to fill lower areas. Based on information in the solicitation documents and prior experience, BH believed the New Hampshire Department of Environmental Sciences would approve a permit for a one-step-cut-to-fill construction plan and calculated its bid price, $238,175,000, accordingly. The contract provided liquidated damages of $8,000 for each day completion was overdue. The NHDES rejected the application. BH advised the government of the implications of NHDES restrictions, but did not refuse to proceed or request that the government intervene with the NHDES. According to BH, the restrictions were contrary to generally accepted industry practice. Upon completion of cut-to-fill operations, BH submitted a Request for Equitable Adjustment, seeking $7,724,885 for excess costs. The Contracting Officer and the Claims Court rejected the request, finding that the Permits and Responsibilities clause placed the burden of obtaining and complying with state and local permits on BH “without additional expense to the Government;” that BH had not alleged violation of the implied duty of good faith; and that, because the government did not control the NHDES, there was no basis for imposing liability for constructive change. The Federal Circuit affirmed. View "Bell/Heery v. United States" on Justia Law

Access sells software for mobile communication, owns the patents at issue, and entered into an exclusive license agreement with APAC, a subsidiary of Acacia. The agreement gave APAC the exclusive right to grant sublicenses, to sue for damages and to seek relief for infringement of the patents. The agreement disclaims third-party-beneficiary rights, states that APAC may not enforce the patents against, or seek licenses to practice the patents from, Access’s customers and end-users in connection with Access’s products and services, and states that APAC and Access consent to the exclusive jurisdiction of any California state or federal court. APAC assigned all of its rights and liabilities in the patents to a wholly owned subsidiary, SmartPhone. SmartPhone sued Huawei, which makes mobile handsets and tablets, in Texas, alleging that Huawei products infringe the patents. Huawei then sued SmartPhone, Acacia Research, and Access in California, alleging that Huawei has been an Access customer for more than 10 years and seeking declaratory judgments of noninfringement. Based on the Texas filing, the district court dismissed the noninfringement and invalidity counts under the first-to-file rule. Dismissing remaining counts, the court stated that.an allegation that the parties intended Huawei to benefit from the license agreement conflicted with its terms. The Federal Circuit affirmed. View "Futurewei Tech., Inc. v. Acacia Research Corp." on Justia Law

Under the Workforce Investment Act, 29 U.S.C. 2887(a)(2)(A), the Department of Labor administers the Job Corps program, providing education, training, and support services to help at-risk youth obtain employment. There are 125 Job Corps Centers, including Blue Ridge in Marion, Virginia, which Res-Care has operated since 1998. In 2011, DOL published a Request for Information from potential bidders on an upcoming procurement for the operation of Blue Ridge. Res-Care’s contract was to expire in 2013. The Request encouraged firms that qualify as small businesses to respond with a “capabilities statement.” One large and four small businesses submitted statements. Res-Care, a large business, did not submit. The contracting officer found that, based on the responses, DOL would likely receive bids from at least two responsible small businesses at fair market prices, as required by the Federal Acquisition Regulation, 38 C.F.R. 19.502-2(b), and recommended conducting the selection as a small business set-aside. DOL issued a presolicitation notice indicating that the next Blue Ridge contract, with a value of $25 million, would be solicited as a “100% Set-Aside for Small Business.” Res-Care filed a bid protest alleging that DOL violated WIA by setting aside the Blue Ridge contract for small businesses, based on the “competitive basis” provision in section 2887. The Claims Court and Federal Circuit upheld the DOL determination.View "Res-Care, Inc. v. United States" on Justia Law

In connection with construction of a pipeline to ship natural gas from Wyoming to Eastern Ohio, Rockies Express and Minerals Management Service (MMS), within the Department of the Interior, entered into contracts containing Royalty-in-Kind (RIK) provisions. Under the RIK program, the government receives its royalty for mineral resources extracted under federal leases “in kind,” i.e., in natural gas, rather than in cash, 30 U.S.C. 192; 42 U.S.C. 15902(b). In exchange, the government makes monthly payments to ensure that a certain quantity of the mineral resources is made available for its purposes. The government then enters into processing and transportation contracts to sell the mineral royalties, often at a substantial profit over royalties received in cash. The Civilian Board of Contract Appeals determined that MMS had materially breached the contract, but that Rockies Express was only entitled to damages that had accrued before the Secretary of the Interior announced a decision to phase-out RIK contracts. The Federal Circuit affirmed that MMS materially breached the contract, but reversed the decision to limit damages. Rockies Express is entitled to compensatory damages to put it in as good a position as that in which it would have been put by full performance of the contract. View "Rockies Express Pipeline, LLC v. Salazar" on Justia Law

In 1997 Wawrzynski was awarded the 990 patent, entitled “Method of Food Article Dipping and Wiping in a Condiment Container.” The description illustrates a condiment container that has a flexible cap with a slitted opening. A user introduces a food article, such as a French fry, into the container through the slit and dips it into the condiment. As the food article is removed, the flexible cap wipes away excess condiment , reducing the likelihood of a drip or spill. . Wawrzynski presented his “Little Dipper” concept, permitting a consumer to either dip or squeeze, to Heinz in a 2008. Heinz indicated that the company was not interested in the product, but months later, released its new “Dip & Squeeze®” packet. Wawrzynski filed a lawsuit asserting breach of an implied contract and unjust enrichment. Heinz counterclaimed that Heinz did not infringe the patent and that the patent was invalid. The district court entered summary judgment, holding that federal patent law preempted the state law claims and that Wawrzynski failed to prove infringement. The Federal Circuit transferred to the Third Circuit, stating that its subject matter jurisdiction over patent disputes derives solely from the complaint, not from any counterclaim. View "Wawrzynski v. H.J. Heinz Co." on Justia Law