Justia Contracts Opinion Summaries

Explosives manufacturer Dyno Nobel tendered an action to its commercial general liability insurance policyholder, Steadfast Insurance Company (“Steadfast”), after being sued in Missouri for damages caused by the release of a nitric oxide plume from one of its Missouri plants. Steadfast denied the claim based on the insurance policy’s clauses precluding indemnification and defense of pollution-related bodily injury actions. Dyno Nobel thereafter filed an action in Utah state court seeking a declaratory judgment that Steadfast had a duty to indemnify and defend against this action under an endorsement titled “Vermont Changes – Pollution” (“Vermont Endorsement”). Contrary to Coverages A, B, and C in the insurance policy, the Vermont Endorsement would have required Steadfast to defend and indemnify against pollution-related bodily injury claims up to an aggregate amount of $3 million. Steadfast removed the action to federal court, and the federal district court entered judgment for Steadfast, concluding the Vermont Endorsement applied only to claims with a nexus to Vermont. Dyno Nobel appealed. After its review, the Tenth Circuit affirmed, finding the plain language of the insurance contract did not cover Dyno Nobel’s claim in the underlying action. View "Dyno Nobel v. Steadfast Insurance Company" on Justia Law

The First Circuit reversed the judgment of the district court concluding that the City of Malden had violated the Massachusetts Wage Act, Mass. Gen. Laws ch. 149, 148 (the Wage Act) and Mass. Gen. Laws ch. 44, 53C (the Municipal Finance Law), holding that there was no violation of the Wage Act or Municipal Finance Law in this case.Plaintiffs, City of Malden police officers, sued the City, arguing that a term in the collective bargaining agreement (CBA) that set the hourly rate for police detail work aligned with how they were historically paid and that a ten percent deduction for an administrative fee resulted in a reduction in their wages as set forth in the CBA, in violation of the Wage Act. The district court ruled that the contract term was ambiguous and, after hearing witness testimony, ruled that the City violated the Municipal Finance Law and the Wage Act. The First Circuit reversed, holding (1) the contract term was unambiguous in favor of the City; (2) any reduction in the calculated rate still resulted in a higher payout than contemplated in the CBA, and therefore, there was no Wage Act violation; and (3) the district court clearly erred in finding that the City had violated the Municipal Finance Law. View "Owens v. City of Malden" on Justia Law

In 2008 Plaintiff Bill Grubb signed an employment agreement with Defendant DXP Enterprises to lead the development and production of horizontal pumps. The agreement recited that the parties intended to create a new company to produce the pumps, and Grubb would own 10%. If the project became a success, Grubb had the right under the employment agreement to require DXP to buy his ownership stake at a price based on the new company’s gross revenue. The project was successful; in March 2019, Grubb gave notice to DXP that he wanted to sell his ownership stake in accordance with the agreement. But DXP informed Grubb it had never formed the new company, so there was nothing for it to purchase under the agreement. Grubb brought this action in the United States District Court for the Northern District of Oklahoma against DXP, asserting claims for breach of contract, actual and constructive fraud, conversion, breach of fiduciary duty, and unjust enrichment; and sought a declaratory judgment. After the parties filed cross-motions for summary judgment, the district court granted summary judgment in favor of DXP on all claims. Grubb appealed. After review, the Tenth Circuit found sufficient evidence of bad faith by DXP (in failing to form the new company) to support Grubb’s breach-of-contract claim but otherwise found no error in the rulings by the district court. Accordingly, the Court reversed in part the judgment below and remanded for further proceedings. View "Grubb v. DXP Enterprises" on Justia Law

The Supreme Court affirmed the judgment of the district court ruling that an Employer's refusal to collect dues from Union members' paychecks was a breach of certain collective bargaining rights and awarding money damages to Union, holding that there was no error.Union brought suit against Employer alleging that Employer breached its contracts by failing to deduct dues. The district court granted summary judgment in favor of Union as to Employer's liability for breach of contract for refusing to deduct dues. After a bench trial on the issue of damages the court awarded $1,046,835 to Union. The Supreme Court affirmed, holding (1) Employer breached the contracts' written terms by failing to collect dues; and (2) the money damages remedy was appropriate and without legal error. View "UE Local 893/IUP v. State" on Justia Law

Defendant resides in Arcadia, California, and holds a Chinese resident identification card. In 2019, Defendant made several trips to Macau, which is an autonomous region on the south coast of China. Gambling is legal in Macau. While in Macau, Defendant entered into seven loan agreements with Tak Chun Gaming Promotion Company Limited (Tak Chun). Tak Chun sued Long in a California state court seeking HK$74,331,320 (that is, US$9,904,787) under causes of action for (1) breach of contract, (2) quantum meruit, and (3) common counts. Following the entry of judgment for Defendant, Tak Chun appealed.   The Second Appellate District affirmed. The court concluded that the common law rule barring resort to the California courts to collect gambling debts rests on a rationale with continued vitality—namely, a policy of discouraging the creation of those debts and the financially ruinous consequences that often flow from them, regardless of whether those debts were lawfully incurred. The court explained that where, as in this case, the lender knows that the money will be used for gambling (as Tak Chun knew because it tendered Defendant casino tokens), the common law rule applies. Lastly, California courts will entertain a lawsuit seeking an accounting following a transaction to sell a casino, but such a lawsuit does not directly involve any gamblers and hence does not hasten any gambler’s financial ruin; while such a lawsuit involves the gambling industry in general, it does not implicate the rationale underlying the common law rule. View "Tak Chun Gaming Promotion Company Limited v. Long" on Justia Law

John Doe (“Appellant”) filed this civil action alleging claims for defamation, abuse of process, tortious interference with contract, intentional infliction of emotional distress, and civil conspiracy against Jane Doe (“Appellee”) after Appellee accused Appellant of sexual assault. When Appellant filed his complaint, he also filed an ex parte motion to proceed using the pseudonym “John Doe” rather than his real name. The district court denied the motion.   The Fourth Circuit affirmed. The court explained that in considering the district court’s entire analysis of the James factors, it concluded that the district court did not abuse its discretion because it did not rely on incorrect factual or legal premises, nor did it give any indication that it was acting by general rule. Instead, the district court conducted a thorough, case-specific analysis when it exercised its discretion. The court wrote that the district court considered each of Appellant’s arguments, and it carefully balanced Appellant’s stated interests against the public’s interest in the openness of judicial proceedings as required by Public Citizen. It did not abuse its discretion in doing so. View "John Doe v. Jane Doe" on Justia Law

Plaintiff appealed from a partial final judgment of the district court dismissing his Connecticut state law claims for defamation and tortious interference with contract against Defendant, who accused Plaintiff of sexual assault in 2015 while the two were students at Yale University. Plaintiff argued that the district court erred in finding (1) Defendant to enjoy absolute quasi-judicial immunity for statements made at the 2018 Yale disciplinary hearing that resulted in Plaintiff’s expulsion from the university and (2) Plaintiff’s tortious interference claims based on Defendant’s original 2015 accusations to be untimely. On preliminary review, the Second Circuit was unable to determine whether Connecticut would recognize the Yale disciplinary hearing at issue as a quasi-judicial proceeding supporting absolute immunity in this case. Accordingly, the court certified questions pertinent to that determination to the Connecticut Supreme Court. That court responded that absolute immunity does not apply in this case because Yale’s disciplinary hearing was not a quasi-judicial proceeding in that it lacked procedural safeguards associated with judicial proceedings.   In response, The Second Circuit affirmed in part, vacated in part, and remanded. The court explained that while the Connecticut Supreme Court recognized the possibility for participants in such a hearing to be shielded by qualified immunity, the Connecticut Supreme Court concluded that Defendant is not presently entitled to dismissal on that ground because Plaintiff’s complaint sufficiently pleads the malice necessary to defeat such immunity. With this guidance as to Connecticut law, the court concluded on this appeal that Plaintiff’s complaint should not have been dismissed against Defendant except as to his tortious interference claim based on 2015 statements, which is untimely. View "Khan v. Yale Univ." on Justia Law

The Supreme Court reversed the judgment of the trial court granting the IU Credit Union's (IUCU) motion to compel individual arbitration and finding an enforceable agreement to arbitrate between the parties, holding that Tonia Land's silence and inaction did not amount to acceptance of the agreement.When Land, who maintained at least two checking accounts with IUCU, registered for online banking for one of her accounts she received by email a an agreement (the disclosure) permitting ICU to modify the terms and conditions to its services and send any notice to Land via email. Under the disclosure, Land was deemed to have received any such notice three days after it was sent. IUCU later sent Land an addendum, which Land claimed never to have received. Land later filed a class action complaint alleging breach of contract and other claims based on the agreement's amendment. IUCU moved to compel individual arbitration, which the trial court granted. The Supreme Court reversed, holding (1) IUCU provided Land with reasonable written notice of its offer to amend the agreement; (2) Land's silence and inaction did not amount to an acceptance of IUCU's offer; and (3) therefore, there was no enforceable agreement to arbitrate. View "Land v. IU Credit Union" on Justia Law

BioCorRx, Inc. (BioCorRx) was a publicly traded company primarily engaged in the business of providing addiction treatment services and related medication. It issued several press releases that allegedly made misrepresentations and improperly disclosed confidential information about a treatment it was developing for opioid overdose. VDM Biochemicals, Inc. (VDM) specializes in the synthesis and distribution of chemicals, reagents, and other specialty products for life science research. It owned a patent (the patent) for VDM-001, a compound with potential use as a treatment for opioid overdose. In September 2018, VDM and BioCorRx entered into a Mutual Nondisclosure & Confidentiality Agreement (the NDA), which restricted each party’s disclosure of confidential information as they discussed forming a business relationship. A month later, VDM and BioCorRx signed a Letter of Intent to Enter Definitive Agreement to Acquire Stake in Intellectual Property (the letter of intent). The letter of intent memorialized the parties’ shared desire whereby BioCorRx would partner with VDM to develop and commercialize VDM-001. BioCorRx and VDM never signed a formal contract concerning VDM-001. Their relationship eventually soured. BioCorRx filed a complaint (the complaint) against VDM; VDM cross-complained. In response, BioCorRx filed the anti-SLAPP motion at issue here, seeking to strike all the allegations from the cross-complaint concerning the press releases. The Court of Appeal found these statements fell within the commercial speech exemption of California's Code of Civil Procedure section 425.16 (the anti-SLAPP statute) because they were representations about BioCorRx’s business operations that were made to investors to promote its goods and services through the sale of its securities. Since these statements were not protected by the anti-SLAPP statute, the Court reversed the part of the trial court’s order granting the anti-SLAPP motion as to the press releases. The Court affirmed the unchallenged portion of the order striking unrelated allegations. View "BioCorRx, Inc. v. VDM Biochemicals, Inc." on Justia Law

Construction firm Brasfield & Gorrie, LLC, received the prime contract to expand the University of Mississippi Medical Center Children’s Hospital in 2017. Electrical contractor McInnis Electric Company secured the winning bid to install the electrical and low voltage systems package for the project and subsequently signed a subcontract with Brasfield & Gorrie. Terms of the subcontract incorporated the prime contract, which were related to the same project by reference. The contract provided that work was set to begin on the project on February 15, 2018. However, McInnis, was directed not to report on site until June 4, 2018, and, due to delays, was unable to begin until July 23, 2018. As work progressed, the schedule allegedly became delayed as a result of Brasfield & Gorrie’s failure to coordinate the work of the various subcontractors. McInnis averred that Brasfield & Gorrie’s failure to coordinate and facilitate the work of the various subcontractors worsened as the project progressed, and Brasfield & Gorrie experienced turnover in management. This failure allegedly delayed McInnis’s work, which was not on the path toward completion, supposedly through no fault of its own. Construction issues were amplified when on March 11, 2020, Mississippi experienced its first reported case of COVID-19. On April 1, 2020, the Mississippi Governor instituted a shelter in place order in response to the ongoing pandemic, requiring certain nonessential businesses to close and recommending social distancing to reduce the spread of the coronavirus in Mississippi. The children’s hospital was not classified as an existing infrastructure as it was a nonoperational work in progress and thus was not subject to the executive order’s exception to the governmental shutdowns. By May 8, 2020, McInnis had suffered an approximately 40 percent loss in its workforce due to employees testing positive for COVID-19. Despite the decrease in the available workforce, Brasfield & Gorrie demanded McInnis perform under its contractual obligation. McInnis took measures to continue the work. Brasfield & Gorrie further declined requests for accommodation and instead terminated McInnis on May 13, 2020. The case before the Mississippi Supreme Court here stemmed from disagreements and a broken contract between the parties, contesting whether arbitration was appropriate to settle their disputes. The trial court compelled arbitration, and the Supreme Court affirmed. View "McInnis Electric Company v. Brasfield & Gorrie, LLC et al." on Justia Law