Justia Contracts Opinion Summaries

Border States Paving was awarded the prime contract by the state DOT for a road project. Border States entered into a subcontract with Morris, Inc. for aggregates and work on the project. During work on the project, the DOT orally informed Morris that certain materials passed the soundness test. However, the materials actually failed. Ultimately, the paving was not completed by the seasonal deadline. When the project was completed the next year, the DOT paid Border States in full. Border States withheld several thousand dollars from Morris for costs associated with the project because it believed Morris defaulted in its contractual obligations under the subcontract. Morris brought suit against the DOT, alleging that the DOT breached its express and implied contractual obligations owed to Morris and that the DOT breached its implied contractual obligation of good faith and fair dealing. The circuit court ruled in favor of Morris and awarded Morris damages. The Supreme Court reversed, holding that there was insufficient evidence that the DOT's erroneous pass report proximately damaged Morris where there was no evidence in the record that this error alone caused the project to not get completed by the deadline.

After Leon Coleman failed to perform eight construction contracts for detached homes, he was convicted of eight counts of theft by deception and eight counts of failure to escrow under Deposits on New Homes Subtitle (Act). The court of special appeals reversed, holding that the Act did not apply and that there was insufficient evidence of intent to support the theft convictions. The Court of Appeals affirmed, holding (1) the evidence was insufficient to conclude that Coleman intentionally deprived buyers of their property, as required under the theft statute; and (2) the plain meaning of the Act indicated that it did not apply to Coleman.

A construction company (Contractor) entered into a contract with the State to restructure an interstate interchange. The contract contained an incentive clause stating that no incentive payment would be made if work was not completed in its entirety by December 15, 2006. After the work was completed, Contractor filed a complaint alleging that the State had breached the contract by refusing to grant an appropriate time extension of the completion date, the disincentive date, and the incentive date. The claims commission (1) found that the contract contained a latent ambiguity requiring extrinsic evidence to interpret the contract, and (2) considered extrinsic evidence in concluding that Contractor was entitled to the maximum incentive payment and an extension of the contract completion date. The court of appeals affirmed. The Supreme Court reversed, holding (1) the contract was unambiguous and did not permit an extension of the incentive date, and (2) therefore, Contractor was not entitled to an incentive bonus. Remanded.

Plaintiffs sued defendant in contract and tort, alleging that defendant failed to take necessary precautions to protect its premises from water damage. At issue on appeal was the trial judge's decision not to grant prejudgment interest on the amounts that were awarded by the jury to plaintiffs. The court held that plaintiffs were entitled to prejudgment interest as a matter of right and remanded to the Superior Court to determine the amount of prejudgment interest owed.

The Weitz Company sued MacKenzie House and MH Metropolitan for breach of construction contract. Arrowhead and Concorde were third-party defendants. MH Metropolitan counterclaimed for breach of the same contract, seeking liquidated damages and the cost to complete the project. Arrowhead also counterclaimed. The jury returned a verdict for MH Metropolitan, Arrowhead, and Concorde on Weitz's claim. The district court denied post-judgment motions and Weitz appealed. The court held that there was a legally sufficient evidentiary basis for the jury's verdict; the district court properly exercised its discretion in excluding the evidence of other projects; the district court correctly decided that the issue of liquidated damages and completion costs were issues of fact that were properly submitted to the jury; there was a legally sufficient evidentiary basis for the district court to deny judgment as a matter of law for Weitz's breach-of-contract claims against Arrowhead; the district court did no err in refusing to enter a default judgment against Concorde when it failed to appear at trial, or in the alternative, refusing to grant Weitz judgment as a matter of law on its claims against Concorde; and because the district court properly found against Weitz on all issues, there was no reason to consider the issue of vicarious liability.

This case arose out of the 2007 collapse of the Interstate 35W Bridge. Individual plaintiffs commenced lawsuits against two contractors that performed work on the bridge pursuant to contracts entered into with the State. The contractors brought third-party complaints against Jacobs Engineering Group on the basis that Jacobs' predecessor negligently designed the bridge. One contractor also filed a third-party complaint against the State. The State cross-claimed against Jacobs for contribution, indemnity, and statutory reimbursement. Jacobs moved to dismiss the State's cross-claim as time-barred, arguing that the reimbursement provision of the compensation statutes compensating survivor-claimants of the collapse did not retroactively revive causes of action against Jacobs that had been previously extinguished by a prior version of the statute of repose. The district court denied the motion, and the court of appeals affirmed. The Supreme Court affirmed, holding (1) the provision retroactively revived the State's action for statutory reimbursement against Jacobs; (2) the provision did not violate Jacob's constitutional right to due process; and (3) revival of the action for statutory reimbursement did not unconstitutionally impair Jacobs' contractual obligations.

This case arose out of the 2007 collapse of the Interstate 35W Bridge. Individual plaintiffs commenced lawsuits against a contractor that performed work on the bridge pursuant to a contract entered into with the State. The contractor brought a third-party complaint against Jacobs Engineering Group for indemnity and contribution on the basis that Jacobs' predecessor negligently designed the bridge. Jacobs moved to dismiss the lawsuits as time-barred and argued that the 2007 amendments to Minn. Stat. 541.051 did not revive actions for contribution or indemnity that had previously been extinguished by a prior version of the statute of repose. The district court denied the motion to dismiss, but the court of appeals reversed. The Supreme Court affirmed the court of appeals, holding that the 2007 amendments to section 541.051 did not retroactively revive the contractor's action for contribution against Jacobs.

Ronald Bacon was injured while working at a construction site. Bacon sued the general contractor, the general contractor's commercial liability insurer, the subcontractor, and the parent company of the subcontractor. Bacon settled with the insurer, which together with the general contractor's separate liability insurer, made payments to Bacon pursuant to the settlement agreement. After Bacon settled with the subcontractor's parent company, the general contractor's two insurers filed a breach of contract action because Bacon received the proceeds of his second settlement but refused to make payment to the insurers under the terms of the first settlement agreement. The district court granted summary judgment for the insurers, finding Bacon, his lawyer, and the lawyer's law firm liable in the amount of $437,500. The Supreme Court reversed the district court's finding that lawyer and law firm were personally liable on the contract, holding that an attorney and/or law firm is not liable on a contract negotiated on behalf of a client when the contract provides that both the client and the attorney "agree to and will pay" a certain sum of money and the attorney signs the contract under the legend "Agreed to in Form & Substance". The Court otherwise affirmed.

Turquoise Properties Gulf, Inc. (Turquoise) appealed a circuit court judgment that denied its motion to alter, amend or vacate an arbitration award in an action filed by Clark A. Cooper, David L. Faulkner, Jr., and Hugh and Adrienne Overmyer (collectively, Claimants). Claimants signed purchase and escrow agreements to purchase condominiums to be built as part of "phase I" of a complex Turquoise was developing in Orange Beach. In conjunction with the purchase, they each posted a letter of credit for 20% of the purchase price. When construction neared substantial completion, the Claimants declined to "close" on the purchases on their respective units, allegedly because Turquoise had failed to build an outdoor pool and sundeck area or to provide individual storage units and private cabanas which it had agreed to build and to provide. The purchase and escrow agreements contained an arbitration provision. Claimants' initial demands contained claims of breach of contract, fraud, and violations of the Interstate Land Sales Full Disclosure Act. The arbitrator entered a lengthy arbitration award containing findings of fact and conclusions of law, ultimately in favor of the Claimants. Turquoise filed a motion to modify the arbitration award on the ground that the arbitrator had made a computational error in his calculation of damages. Upon review, the Supreme Court concluded that the arbitrator did mistakenly calculate damages owed to the claimants. The Court vacated the arbitrator's award and remanded the case for recalculation of damages.

Frederick and Mandelena Harmon bought a home pursuant to a buy-sell agreement that realtor Dianne Burright, a licensed real estate salesperson who worked for Fiscus Realty, prepared at the Fiscus Realty office. The home was built by Dianne's husband, Jerry. The Harmons subsequently discovered numerous construction problems. The Harmons sued Defendants Jerry and Dianne Burright and Fiscus Reality, raising several causing of action, including a claim under the Unfair Trade Practices and Consumer Protection Act (the Act). A jury returned a verdict against the Burrights on breach of warranty and negligent misrepresentation claims and held for Defendants on all other claims. After trial, Defendants filed motions for attorney fees as prevailing parties under the Act, which the district court denied. Fiscus Realty appealed. The Supreme Court affirmed, holding that the district court did not abuse its discretion in denying an award of attorney fees to Fiscus Realty as the Harmons' claims had a basis in fact and law and were not frivolous, unreasonable or unfounded.