Justia Contracts Opinion Summaries

In 1999, Redondo Construction Corporation pled guilty to aiding and abetting the making of false statements during its work on a federal highway project. The Puerto Rico Highway and Transportation Authority (“PRHTA”) and the Puerto Rico Public Guildings Authority (“PBA”) subsequently revoked the bids it had awarded Redondo before the plea and suspended Redondo from bidding on new contracts. Redondo challenged both decisions, which resulted in settlement agreements with both agencies allowing Redondo to resume bidding for contracts. After Puerto Rico passed Law 458, which prohibited Puerto Rico agencies from awarding contracts corporations convicted of offenses involving public funds, the PBA cancelled several of Redondo’s bids and the contract it had executed with Redondo, and the PRHTA withdrew from its settlement with Redondo. Redondo sued PRHTA, PBA, and several officials at both agencies, alleging that Defendants were in breach of the settlement agreements, that this caused Redondo’s bankruptcy, and that Defendants were liable in damages. The district court granted the PRHTA’s and the individual defendants’ motions for summary judgment and sua sponte dismissed Redondo’s claims against the PBA. The First Circuit Court of Appeals (1) affirmed the entry of summary judgment as to the PRHTA and the individual defendants, as Redondo had no record of evidence of damages against these defendants; but (2) vacated the dismissal of the claim against the PBA, as the court did not meet the necessary conditions for entering judgment sua sponte. View "Redondo Constr. Corp. v. Izquierdo" on Justia Law

Appellant Edged in Stone, Inc. (EIS) sought damages for breach of contract, breach of warranty, breach of implied covenant of good faith and fair dealing, negligence and unjust enrichment when a skid loader it purchased experienced mechanical problems. The district court dismissed all of EIS's claims except breach of contract and unjust enrichment. Later, the district court entered a judgment in favor of Northwest Power Systems, LLC (NWPS), dismissing EIS's remaining claims and awarded NWPS attorney's fees and costs. EIS appealed to the Supreme Court, arguing arguing that the district court erred in granting summary judgment to NWPS. After careful consideration of the trial court record, the Supreme Court found no reversible error and affirmed that court's grant of summary judgment. View "Edged In Stone v. NW Power Systems" on Justia Law

Carnell, a "minority-owned" corporation, filed suit against the Housing Authority and Blaine based on claims of race discrimination, retaliation, and breach of contract. The court held that a corporation can acquire a racial identity and establish standing to seek a remedy for alleged race discrimination under Title VI of the Civil Rights Act of 1964, 42 U.S.C. 2000d, but that the district court properly dismissed one of the defendants from liability on plaintiff's race discrimination claims; the district court abused its discretion in permitting the use of particular impeachment evidence, which should have been excluded as unfairly prejudicial under Federal Rule of Evidence 403; and the district court properly reduced certain damages awarded to plaintiff on its contract claims, but decided that the strict notice requirements of the Virginia Public Procurement Act, Virginia Code 2.2-4300 through 4377, required the court to narrow further the scope of recoverable contract damages. Accordingly, the court affirmed in part, vacated in part, and remanded for further proceedings. View "Carnell Construction Corp. v. Danville RHA" on Justia Law

Downing, Thorpe & James Design, Inc. (DTJ) was an architectural firm incorporated in Colorado. Thomas Thrope, one of DTJ’s three founding principals, was allowed to practice individually as a foreign architect in Nevada, but DTJ was not allowed to practice as a foreign corporation in Nevada. In 2004, DTJ contracted with a Nevada developer to provide architectural services for a Las Vegas subdivision owned by Prima Condominiums, LLC (Prima). Prima obtained a loan from First Republic Bank in exchange for a promissory note secured by a deed of trust on one of the subdivision’s units. After Prima defaulted on its payments, DTJ recorded a notice of mechanic’s lien against the property for unpaid services. First Republic then foreclosed and purchased the property. DTJ subsequently brought an action against First Republic for lien priority and unjust enrichment. The district court granted summary judgment for First Republic. The Supreme Court affirmed, holding (1) because DTJ had failed to comply with Nevada’s statutory registration and filing provisions, it was barred from maintaining an action in Nevada for compensation for its architectural services; and (2) Thorpe’s individual status had no bearing on whether DTJ could bring or maintain an action for compensation for its services. View "DTJ Design, Inc. v. First Republic Bank" on Justia Law

VP & PK purchased an insurance policy from Lexington Insurance Company for work on a construction site. Kila Kila, one of VP & PK’s subcontractors, purchased an insurance policy from Nautilus Insurance Company. Both policies contained an “other insurance” provision and included duties to defend and indemnify. When VP & PK and Kila Kila were sued for damages resulting from the construction, Nautilus funded the defense of both Kila Kila and VP & PK. Lexington satisfied the judgment against VP & PK but did not contribute to the defense costs. Nautilus filed a complaint seeking (1) a declaration that Lexington owed VP & PK a duty to defend, which it breached; and (2) equitable contribution from Lexington for defense costs. The U.S. district court granted summary judgment for Lexington, holding that Lexington’s policy was in excess to Nautilus’s policy, and therefore, Lexington’s duty to defend was not triggered. The Hawaii Supreme Court accepted certified questions from the court of appeals and held, inter alia, that (1) an “other insurance” clause purporting to release an otherwise primary insurer of the duty to defend if the insurer becomes excess as to liability is enforceable, but only as between two or more insurers seeking to allocate or recover defense costs; and (2) an otherwise primary insurer who becomes an excess insurer by operation of an “other insurance” clause has a duty to defend as soon as a claim is tendered to it and there is the mere possibility that coverage of that claim exists under its policy. View "Nautilus Ins. Co. v. Lexington Ins. Co." on Justia Law

In 2002, the Navy awarded Metcalf a contract to design and build 212 housing units in Hawaii by October, 2006, for $50 million. Problems arose involving soil conditions. The request for proposals stated that the “soil reconnaissance report” was “for preliminary information only” and required that the contractor conduct independent soil investigation, incorporating 48 C.F.R. 52.236-2, concerning site conditions that differ materially from those disclosed. Discussions delayed construction for a year. Metcalf implemented its preferred changes by over-excavating and using non-expansive fill, without a contract modification. The Navy denied that there was any material difference between pre-bid and post-award soil assessments, but approved some modifications. Metcalf was about 200 days behind schedule and began using “post-tension” concrete, which was more expensive but avoided the additional time and cost of over-excavation. The Navy amended the contract to approve use of post-tension concrete slabs. Metcalf claims additional delays resulting from the presence of more of a chemical contaminant than was expected. With respect to contamination, the Navy granted a 286-day extension and reimbursed $1,493,103. The Navy accepted the buildings in March, 2007. Metcalf alleged that its final cost was $76 million. The government paid less than $50 million. The Claims Court ruled in favor of the government, under the Contract Disputes Act, 41 U.S.C. 7104. The Federal Circuit vacated, holding that the court misconstrued what Metcalf needed to show to prove that the government breached its duty of good faith and fair dealing and misinterpreted certain contractual provisions.View "Metcalf Const. Co., LLC v. United States" on Justia Law

ICI Homes, Inc. (ICI) had a general liability insurance policy with General Fidelity Insurance Company. In 2007, Katherine Ferrin, the owner of a residence constructed by ICI, was injured while using stairs installed by Custom Cutting, Inc. Ferrin filed suit against ICI. ICI, in turn, sought indemnification from Custom Cutting. The parties agreed to a $1.6 million settlement of Ferrin’s claim. ICI accepted $1 million from Custom Cutting’s insurer to settle its indemnification claim, which it paid to Ferrin. ICI and General Fidelity then claimed the other was responsible for paying Ferrin the remaining $600,000. Both parties paid $300,000 to Ferrin to settle Ferrin’s claim. ICI then filed suit against General Fidelity seeking return of the $300,000 ICI paid above the $1 million indemnification payment. General Fidelity counterclaimed seeking return of the $300,000 it had paid to Ferrin. The district court entered judgment for General Fidelity. The court of appeals certified two questions to the Supreme Court for resolution. The Supreme Court answered (1) the General Fidelity policy allowed ICI to apply indemnification payments received from Custom Cutting’s insurer towards satisfaction of its $1 million self-insured retention; and (2) the transfer of rights provision in the policy did not abrogate the made whole doctrine. View "Intervest Constr. of Jax, Inc. v Gen. Fidelity Ins. Co." on Justia Law

In 2001 KBR agreed to provide the Army with logistics support services during Operation Iraqi Freedom. Individual task orders required KBR to install, operate and maintain dining services near Mosul, Iraq on a cost-plus-award-fee basis. KBR selected ABC, a subcontractor, to build a prefabricated metal dining facility and to provide dining services for a camp population of 2,573. In June 2004, the Army ordered KBR to stop construction of the metal facility and begin construction of a reinforced concrete facility for an estimated 2,573 to 6,200+ persons. Instead of requesting bids for the new work, KBR kept ABC as the subcontractor due to the urgency of the request. ABC submitted a new proposal with a total monthly cost about triple the monthly cost initially quoted. ABC attributed the increased costs to additional labor and equipment to serve a larger population and to a drastic increase in the cost of labor and a severe shortage of staff willing to work in Iraq. Due to a calculation error, it was determined that ABC’s proposal was reasonable. KBR’s management reviewed and approved a change order, embodying ABC’s proposal. In 2005 the subcontract ended and title to the dining facility passed to the Army. In 2007, the Defense Contract Auditing Agency suspended payment of certain costs paid by KBR to ABC pursuant to the change order. KBR prepared a new price justification for the concrete dining facility and ultimately filed suit, seeking recovery of the $12,529,504 in costs disapproved for reimbursement. The Claims Court awarded $6,779,762. The Federal Circuit affirmed.View "Kellogg Brown & Root Servs. v. United States" on Justia Law

Morrison-Maierle, Inc. (MMI) was hired by two counties to provide engineering services and supervision on a road improvement contract. The counties retained JEM Contracting, Inc. (JEM) to provide the construction services on the project. JEM filed suit against MMI alleging detrimental reliance and fraudulent inducement for promises MMI allegedly made during the job that JEM would be paid for unanticipated costs incurred during pulverization of the old road. The district court granted summary judgment for MMI, concluding that JEM could not prove it had been harmed by MMI’s alleged representations. The Supreme Court affirmed, holding that the district court did not err by (1) concluding that JEM was required to continue performance pending approval of a change order under a certain contract provision, as the provision was not void as against public policy; and (2) granting summary judgment to MMI on the ground that JEM failed to show it was harmed by the representations made by MMI. View "JEM Contracting, Inc. v. Morrison-Maierle, Inc." on Justia Law

In 1998 the Gillespie School District hired Wight under for services preliminary to the actual designing and construction of a new elementary school building. Wight agreed to perform a “site mine investigation.” Wight hired Hanson Engineers to assess the potential for coal mine subsidence. A physical engineer at Hanson sent a letter to Wight, noting recorded subsidence events, including five to six events since 1979, affecting more than 40 structures in the area. The letter stated: “No one can predict when or if the land above the roof-and-pillar mine will subside… The owner should consider the fact that there is no economically feasible corrective action… to guarantee against future subsidence… it can be intuitively concluded that there is a relatively high risk of subsidence in the Benld/Gillespie area. The letter was not attached to the report, which noted some of its highlights. The school was built and occupied, but in 2009 was severely damaged as the result of subsidence and was condemned. The District sued Wight, alleging professional negligence, breach of implied warranty, and fraudulent misrepresentation by concealment of material fact. The court entered summary judgment in favor of Wight, based on statutes of limitations applicable to the claims. The appellate court affirmed. The Illinois Supreme Court affirmed, noting that it was expressing no opinion concerning the merits of various claims. View "Gillespie Cmty. Unit Sch. Dist. No. 7 v. Wight & Co." on Justia Law