Justia Contracts Opinion Summaries

This case centers on a contractor’s claim for a Type I differing site condition relating to a flood control project in Jefferson Parish, Louisiana. The United States Army Corps of Engineers issued a solicitation for work on the Trapp Canal, which included boring logs and cross-sections of the canal but lacked specific information about the southwest bank. Hamp’s Construction LLC, after being awarded the contract, encountered unexpected bank failures in the southwest quadrant, resulting in unsafe conditions for land-based equipment and significant delays. Hamp’s Construction submitted a request for equitable adjustment and later a formal claim, asserting that the conditions encountered were materially different from those indicated in the contract documents.The contracting officer denied Hamp’s Construction’s request and subsequent claim, concluding there was insufficient proof of a differing site condition under the relevant Federal Acquisition Regulation clause. Hamp’s Construction appealed to the Armed Services Board of Contract Appeals. After a hearing, the Board found that although Hamp’s Construction had faced unforeseen difficulties and increased costs, the contract documents did not provide representations or indications about the subsurface conditions of the southwest bank. The Board emphasized the absence of boring logs or explicit information for the area where the failures occurred and denied the appeal.The United States Court of Appeals for the Federal Circuit reviewed the Board’s legal conclusions de novo and factual findings for substantial evidence. The court held that, for a Type I differing site condition claim, the contract must affirmatively indicate conditions at the disputed site. The court determined that Hamp’s Construction could not reasonably rely on contract documents as indications for the southwest bank. The court affirmed the Board’s decision, holding that Hamp’s Construction failed to establish a threshold element of a Type I differing site condition claim. View "HAMP'S CONSTRUCTION LLC v. SECRETARY OF THE ARMY" on Justia Law

A general contractor and a subcontractor entered into agreements for the construction and renovation of a facility. The subcontracts required disputes to be resolved by arbitration pursuant to the rules of the American Arbitration Association. The subcontractor performed work and submitted invoices, but the general contractor, while timely rejecting the invoices and providing reasons, failed to include the good faith certification required by the Massachusetts prompt pay act. The contractor later paid the invoices after an arbitrator determined that the invoices were deemed approved due to the lack of timely certification. Subsequently, the contractor filed a counterclaim in arbitration seeking recoupment of those payments, arguing the invoices were not fair and reasonable.The subcontractor initially brought suit in the Massachusetts Superior Court, which was then compelled to arbitration per the contract. During arbitration, the arbitrator found that the contractor’s failure to timely certify its rejection of the invoices resulted in the invoices being deemed approved and ordered payment to the subcontractor. After payment, the arbitrator allowed the contractor’s counterclaim for recoupment. Following evidentiary proceedings, the arbitrator ruled in favor of the contractor, awarding partial recoupment. The subcontractor moved in the Superior Court to vacate this award, arguing that the arbitrator exceeded his authority. Relying on J.C. Cannistraro, LLC v. Columbia Construction Co., the Superior Court judge vacated the recoupment portion of the arbitration award, finding that the contractor had asserted defenses before paying the invoices, contrary to precedent.The Supreme Judicial Court of Massachusetts reviewed the matter on direct appellate review. It held that the arbitrator did not exceed his authority because the award was not prohibited by law nor did it violate public policy. The court determined that the prompt pay act did not expressly prohibit recoupment in these circumstances and that the arbitrator’s actions were within the broad scope granted by the parties’ agreement and the arbitration rules. The judgment vacating the arbitration award was reversed and the matter remanded for confirmation of the arbitration award. View "J.C. Cannistraro, LLC v. Columbia Construction Co." on Justia Law

After her property experienced water intrusion, a homeowner sued her neighbor, whose property was the source of the problem. The neighbor, in defending the lawsuit, hired a construction consulting firm to inspect both properties and to create an expert report recommending repairs. The recommendations from this report formed the basis of a settlement between the homeowner and her neighbor, and repairs were performed accordingly. After the settlement and repairs, the water intrusion problem recurred, leading the homeowner to file a new lawsuit against the consulting firm, alleging that its recommendations were negligent and defective.In the Superior Court of Orange County, the consulting firm filed an anti-SLAPP motion, asserting that its actions were protected as statements made in the course of litigation. The trial court granted the motion concerning certain claims, but denied it for claims of negligence and breach of contract as a third-party beneficiary, reasoning these arose from conduct rather than protected statements. On appeal, the California Court of Appeal previously affirmed the trial court’s partial denial, finding that the remaining claims were not based on protected activity, and remanded for further proceedings on those claims.Upon remand, the consulting firm moved for judgment on the pleadings, contending that the litigation privilege under California Civil Code section 47(b) barred the remaining claims. The California Court of Appeal, Fourth Appellate District, Division Three, affirmed the trial court’s judgment in favor of the consulting firm. The court held that the litigation privilege applied because the firm’s formulation of repair recommendations was necessarily related to a communicative act (the expert report) prepared in the course of litigation, and thus barred the homeowner’s negligence and third-party beneficiary claims. The judgment in favor of the consulting firm was affirmed. View "Fazel v. Pete Fowler Construction Services" on Justia Law

A Mississippi construction company, operating under the name MCA Construction, Inc., entered into a contract with an Alabama property owner to perform site development work on a residential subdivision in Baldwin County. The contract was executed on February 11, 2021, and at that time, the company held an Alabama general contractor’s license with a “Building Construction” (BC) classification and an unlimited bid limit. Shortly before executing the contract, the city engineer raised questions regarding whether the BC classification was adequate for the planned utility work (such as water and sewer installation) and indicated that an additional “Municipal and Utility” (MU) classification might be required before such work began. MCA sought clarification from the state licensing board and subsequently obtained the MU classification in May 2021, before starting the utility work.The property owner, RAM-Robertsdale Subdivision Partners, LLC, along with related parties, later alleged that MCA had performed defective work and failed to pay subcontractors, and they brought suit in Baldwin Circuit Court. MCA filed counterclaims for breach of contract and fraud, asserting that it had not been fully paid for its work. The RAM parties moved for summary judgment, arguing that the contract was void because MCA was not properly licensed with the MU classification at the time the contract was executed.The Baldwin Circuit Court granted summary judgment for the RAM parties, holding that the contract was void because MCA was not “duly licensed” for all aspects of the work at the time of contracting. MCA appealed. The Supreme Court of Alabama reviewed the statutory and regulatory framework, noting that MCA had a valid BC license, acted in good faith, and obtained the MU classification before performing utility work. The Supreme Court of Alabama held that substantial compliance with the licensing statute was sufficient in these circumstances and that voiding the contract was not warranted. The court reversed the summary judgment and remanded for further proceedings. View "Construction Services, LLC v. RAM-Robertsdale Subdivision Partners, LLC" on Justia Law

A developer owned all property in a residential community and petitioned a town to create a public improvement district to finance and construct infrastructure improvements, such as roads and water lines. The district’s board, composed of representatives of the developer, was authorized to levy assessments and issue bonds to fund construction. The developer and the district entered a development agreement requiring the developer to fund the improvements, and the district contracted with a construction company to perform the work. After most of the work was done, a payment dispute arose. The construction company obtained an arbitration award against the district but was not fully paid. The construction company then sued the developer and related entities for unjust enrichment, asserting that the developer received the benefit of infrastructure improvements without paying for them.The Superior Court in Maricopa County granted the developer’s motion to dismiss, concluding that, under Arizona law as interpreted in Wang Electric, Inc. v. Smoke Tree Resort, a plaintiff in an unjust enrichment claim must allege improper conduct by the property owner, and the construction company had not done so. The court also denied the construction company’s request to file an amended complaint. The Arizona Court of Appeals reversed, holding that the improper conduct requirement applied only in landlord-tenant-contractor cases, and allowed the construction company to amend its complaint.The Supreme Court of the State of Arizona reviewed the case to clarify when the improper conduct requirement applies to unjust enrichment claims. The court held that the requirement only applies when the owner is a landlord and the improvements are made at the tenant’s direction. It does not extend to situations where the owner directly arranges for improvements and pays no one for them. The court concluded that the construction company’s allegations were sufficient to state a claim for unjust enrichment against the developer. The court vacated the decision of the court of appeals, reversed the superior court’s dismissal, and remanded for further proceedings. View "MARKHAM v. CAHAVA" on Justia Law

A regional airport authority undertook a project to remove a hill from land owned by a private property holder. Instead of purchasing the land outright, the parties entered into an agreement allowing the airport authority to remove the hill and, afterwards, to further lower the elevation of the property by overblasting, which would make future development easier for the owner. The airport authority completed the hill removal but failed to perform the overblasting. The landowner then sued for breach of contract, seeking damages for the incomplete work.The United States District Court for the Southern District of West Virginia found that the airport authority had breached the agreement and granted partial summary judgment to the landowner on liability. Both sides submitted expert reports concerning the cost to complete the required overblasting, ultimately agreeing that this cost was over $4 million. However, the district court held that the cost of completion was grossly disproportionate to the value of the property and applied the “gross disproportionality” rule, awarding only nominal damages because it found insufficient evidence of the property’s diminution in value. The landowner appealed, and the United States Court of Appeals for the Fourth Circuit certified to the Supreme Court of Appeals of West Virginia the question of whether, how, and by whom the gross disproportionality rule should be applied in such cases.The Supreme Court of Appeals of West Virginia held that, in breach of construction contract cases, the gross disproportionality rule may be applied to limit damages. The court clarified that gross disproportionality is calculated using the diminution in value approach, measuring the difference in value between the property as is and as it should have been if the contract had been fully performed. The court further held that the breaching party bears the burden of invoking and proving gross disproportionality. If the breaching party fails to meet this burden, the non-breaching party’s proven measure of damages applies. View "Corotoman, Inc. v. Central West Virginia Regional Airport Authority" on Justia Law

A county entered into a contract in the late 1970s with various firms for the construction of a new jail, which was completed in 1981. Decades later, during a renovation in 2021, a construction defect was discovered: the original roof was not properly attached to the masonry walls. The county paid for repairs and, in 2023, sued the original architect, the general contractor, and the masonry subcontractor for negligence, fraudulent misrepresentation or nondisclosure, and breach of contract. Each defendant raised the statute of repose in 42 Pa.C.S. § 5536 as a defense, arguing the claims were filed more than 12 years after completion of the jail.The Court of Common Pleas of Clearfield County sustained the defendants’ preliminary objections, finding the statute of repose applied because the jail was completed in 1981, and the defendants had performed the qualifying construction services. The court further held that the doctrine of nullum tempus occurrit regi, which sometimes allows government entities to avoid statutes of limitations, did not apply to the statute of repose. The county appealed.The Commonwealth Court affirmed, assuming for argument's sake that nullum tempus could apply to statutes of repose, but concluding the county failed to meet the requirements for invoking the doctrine because constructing the jail was not enforcing an obligation imposed by law.Upon further appeal, the Supreme Court of Pennsylvania held that nullum tempus cannot preclude the application of the Section 5536 statute of repose. The court concluded the statute of repose is a legislative judgment eliminating liability for construction professionals after 12 years, and its purpose cannot be undermined by the common law doctrine of nullum tempus. The Supreme Court affirmed the Commonwealth Court’s order upholding dismissal of the complaint. View "Clearfield County v. Transystems Corp." on Justia Law

The dispute arose from a contract in which a company specializing in vehicle emissions testing equipment agreed to supply and install its products in a facility being constructed by a general contractor for a state agency. After receiving substantial payments, the equipment supplier sought additional compensation through arbitration. The general contractor defended by arguing that the supplier was not properly licensed as required by California’s Contractors State Licensing Law (CSLL), and thus could not recover payment. The supplier then initiated a lawsuit seeking a judicial declaration that it was exempt from the CSLL’s licensing requirements because its equipment did not become a “fixed part of the structure,” referencing an exemption in the law.The Superior Court of Riverside County reviewed cross-motions for summary judgment. The general contractor argued the exemption did not apply because the equipment became permanently affixed to the building, and the supplier had performed work before obtaining a license. The supplier contended its products were portable and not intended to be permanent fixtures, and that it acted as an equipment installer exempt under the law. The superior court granted summary judgment for the general contractor, finding that the evidence showed the equipment did become a fixed part of the structure and thus the supplier needed a contractor’s license.On appeal, the California Court of Appeal, Fourth Appellate District, Division One, found the lower court erred by deciding as a matter of law that the exemption did not apply. The appellate court held that whether the equipment became a fixed part of the structure is a factual question, not one suitable for summary judgment on the record before it. Because there was conflicting evidence—including expert declarations—on this issue, the trial court should have permitted the factual dispute to be resolved by a trier of fact. The appellate court reversed the judgment and remanded the case for further proceedings. View "AVL Test Systems v. Hensel Phelps Construction" on Justia Law

Cuevas Machine Company entered into a subcontract with O’Neal Constructors for fabrication and machining work at a filtration plant owned by Calgon Carbon Corporation in Mississippi. Under the subcontract, Cuevas was to be paid after Calgon paid O’Neal. Despite nonpayment from O’Neal, Cuevas continued its work. In October 2023, Cuevas recorded two construction liens totaling over $1.2 million against Calgon’s property, but the lien documents did not explicitly state the last date labor, services, or materials were supplied—a statutory requirement. Instead, Cuevas attached invoices to the liens, which included dates, but it was unclear whether these dates satisfied the statutory requirement.After Cuevas filed suit to foreclose on the liens in Mississippi state court, Calgon removed the case to the United States District Court for the Southern District of Mississippi and moved to dismiss. The district court granted Calgon’s motion, dismissing Cuevas’s complaint with prejudice under Rule 12(b)(6). The district court concluded, making an Erie guess, that the liens were unenforceable because they did not clearly specify the required “last date” in the manner demanded by Mississippi law, and found that the attached invoices did not sufficiently cure this defect.On appeal, the United States Court of Appeals for the Fifth Circuit reviewed the district court’s decision de novo. Finding Mississippi law ambiguous on whether attachments that do not plainly state the “last date” can satisfy the statutory requirement, the Fifth Circuit certified the following question to the Mississippi Supreme Court: whether attaching invoices that do not explicitly state the “last date labor, services or materials were supplied” satisfies the requirement under Miss. Code Ann. § 85-7-405(1)(b) that a lien “specify the date the claim was due.” The Fifth Circuit did not decide the merits, instead certifying the question for authoritative resolution. View "Cuevas Machine v. Calgon Carbon" on Justia Law

A public entity contracted with a general contractor to construct a major rail line project. The general contractor, in turn, subcontracted a significant portion of the work to a subcontractor. As the project progressed, it experienced numerous delays and disruptions, which the subcontractor claimed increased its costs. After completing its performance, the subcontractor, relying on expert analysis of its additional costs, filed a verified statement of claim under the Colorado Public Works Act, asserting it was owed additional millions for labor, materials, and other costs, including those stemming from delay and disruption.Following the filing, the general contractor substituted a surety bond for the retained project funds and the subcontractor initiated litigation in Denver District Court. After a bench trial, the trial court found in favor of the subcontractor, concluding that its verified statement of claim was not excessive and that there was a reasonable possibility the claimed amount was due. The court awarded the subcontractor damages for delay, disruption, and unpaid funds. The general contractor appealed, contending the claim was excessive and should result in forfeiture of all rights to the claimed amount. The Colorado Court of Appeals reversed in relevant part, holding that the verified statement of claim was excessive as a matter of law and that the subcontractor forfeited all rights to the amount claimed. This disposition left certain issues raised by the subcontractor on cross-appeal unaddressed.The Supreme Court of Colorado granted review and held that, under the Public Works Act, disputed or unliquidated amounts—including delay and disruption damages—may be included in a verified statement of claim if they represent the specified categories of costs and the claim is not excessive under the statute. The court also held that filing an excessive claim results only in forfeiture of statutory remedies under the Act, not all legal remedies. The Supreme Court reversed the Court of Appeals’ judgment and remanded for further proceedings. View "Ralph L. Wadsworth Constr. Co. v. Reg'l Rail Partners" on Justia Law