Justia Contracts Opinion Summaries

Explosives manufacturer Dyno Nobel tendered an action to its commercial general liability insurance policyholder, Steadfast Insurance Company (“Steadfast”), after being sued in Missouri for damages caused by the release of a nitric oxide plume from one of its Missouri plants. Steadfast denied the claim based on the insurance policy’s clauses precluding indemnification and defense of pollution-related bodily injury actions. Dyno Nobel thereafter filed an action in Utah state court seeking a declaratory judgment that Steadfast had a duty to indemnify and defend against this action under an endorsement titled “Vermont Changes – Pollution” (“Vermont Endorsement”). Contrary to Coverages A, B, and C in the insurance policy, the Vermont Endorsement would have required Steadfast to defend and indemnify against pollution-related bodily injury claims up to an aggregate amount of $3 million. Steadfast removed the action to federal court, and the federal district court entered judgment for Steadfast, concluding the Vermont Endorsement applied only to claims with a nexus to Vermont. Dyno Nobel appealed. After its review, the Tenth Circuit affirmed, finding the plain language of the insurance contract did not cover Dyno Nobel’s claim in the underlying action. View "Dyno Nobel v. Steadfast Insurance Company" on Justia Law

In 2008 Plaintiff Bill Grubb signed an employment agreement with Defendant DXP Enterprises to lead the development and production of horizontal pumps. The agreement recited that the parties intended to create a new company to produce the pumps, and Grubb would own 10%. If the project became a success, Grubb had the right under the employment agreement to require DXP to buy his ownership stake at a price based on the new company’s gross revenue. The project was successful; in March 2019, Grubb gave notice to DXP that he wanted to sell his ownership stake in accordance with the agreement. But DXP informed Grubb it had never formed the new company, so there was nothing for it to purchase under the agreement. Grubb brought this action in the United States District Court for the Northern District of Oklahoma against DXP, asserting claims for breach of contract, actual and constructive fraud, conversion, breach of fiduciary duty, and unjust enrichment; and sought a declaratory judgment. After the parties filed cross-motions for summary judgment, the district court granted summary judgment in favor of DXP on all claims. Grubb appealed. After review, the Tenth Circuit found sufficient evidence of bad faith by DXP (in failing to form the new company) to support Grubb’s breach-of-contract claim but otherwise found no error in the rulings by the district court. Accordingly, the Court reversed in part the judgment below and remanded for further proceedings. View "Grubb v. DXP Enterprises" on Justia Law

Defendant resides in Arcadia, California, and holds a Chinese resident identification card. In 2019, Defendant made several trips to Macau, which is an autonomous region on the south coast of China. Gambling is legal in Macau. While in Macau, Defendant entered into seven loan agreements with Tak Chun Gaming Promotion Company Limited (Tak Chun). Tak Chun sued Long in a California state court seeking HK$74,331,320 (that is, US$9,904,787) under causes of action for (1) breach of contract, (2) quantum meruit, and (3) common counts. Following the entry of judgment for Defendant, Tak Chun appealed.   The Second Appellate District affirmed. The court concluded that the common law rule barring resort to the California courts to collect gambling debts rests on a rationale with continued vitality—namely, a policy of discouraging the creation of those debts and the financially ruinous consequences that often flow from them, regardless of whether those debts were lawfully incurred. The court explained that where, as in this case, the lender knows that the money will be used for gambling (as Tak Chun knew because it tendered Defendant casino tokens), the common law rule applies. Lastly, California courts will entertain a lawsuit seeking an accounting following a transaction to sell a casino, but such a lawsuit does not directly involve any gamblers and hence does not hasten any gambler’s financial ruin; while such a lawsuit involves the gambling industry in general, it does not implicate the rationale underlying the common law rule. View "Tak Chun Gaming Promotion Company Limited v. Long" on Justia Law

John Doe (“Appellant”) filed this civil action alleging claims for defamation, abuse of process, tortious interference with contract, intentional infliction of emotional distress, and civil conspiracy against Jane Doe (“Appellee”) after Appellee accused Appellant of sexual assault. When Appellant filed his complaint, he also filed an ex parte motion to proceed using the pseudonym “John Doe” rather than his real name. The district court denied the motion.   The Fourth Circuit affirmed. The court explained that in considering the district court’s entire analysis of the James factors, it concluded that the district court did not abuse its discretion because it did not rely on incorrect factual or legal premises, nor did it give any indication that it was acting by general rule. Instead, the district court conducted a thorough, case-specific analysis when it exercised its discretion. The court wrote that the district court considered each of Appellant’s arguments, and it carefully balanced Appellant’s stated interests against the public’s interest in the openness of judicial proceedings as required by Public Citizen. It did not abuse its discretion in doing so. View "John Doe v. Jane Doe" on Justia Law

BioCorRx, Inc. (BioCorRx) was a publicly traded company primarily engaged in the business of providing addiction treatment services and related medication. It issued several press releases that allegedly made misrepresentations and improperly disclosed confidential information about a treatment it was developing for opioid overdose. VDM Biochemicals, Inc. (VDM) specializes in the synthesis and distribution of chemicals, reagents, and other specialty products for life science research. It owned a patent (the patent) for VDM-001, a compound with potential use as a treatment for opioid overdose. In September 2018, VDM and BioCorRx entered into a Mutual Nondisclosure & Confidentiality Agreement (the NDA), which restricted each party’s disclosure of confidential information as they discussed forming a business relationship. A month later, VDM and BioCorRx signed a Letter of Intent to Enter Definitive Agreement to Acquire Stake in Intellectual Property (the letter of intent). The letter of intent memorialized the parties’ shared desire whereby BioCorRx would partner with VDM to develop and commercialize VDM-001. BioCorRx and VDM never signed a formal contract concerning VDM-001. Their relationship eventually soured. BioCorRx filed a complaint (the complaint) against VDM; VDM cross-complained. In response, BioCorRx filed the anti-SLAPP motion at issue here, seeking to strike all the allegations from the cross-complaint concerning the press releases. The Court of Appeal found these statements fell within the commercial speech exemption of California's Code of Civil Procedure section 425.16 (the anti-SLAPP statute) because they were representations about BioCorRx’s business operations that were made to investors to promote its goods and services through the sale of its securities. Since these statements were not protected by the anti-SLAPP statute, the Court reversed the part of the trial court’s order granting the anti-SLAPP motion as to the press releases. The Court affirmed the unchallenged portion of the order striking unrelated allegations. View "BioCorRx, Inc. v. VDM Biochemicals, Inc." on Justia Law

Construction firm Brasfield & Gorrie, LLC, received the prime contract to expand the University of Mississippi Medical Center Children’s Hospital in 2017. Electrical contractor McInnis Electric Company secured the winning bid to install the electrical and low voltage systems package for the project and subsequently signed a subcontract with Brasfield & Gorrie. Terms of the subcontract incorporated the prime contract, which were related to the same project by reference. The contract provided that work was set to begin on the project on February 15, 2018. However, McInnis, was directed not to report on site until June 4, 2018, and, due to delays, was unable to begin until July 23, 2018. As work progressed, the schedule allegedly became delayed as a result of Brasfield & Gorrie’s failure to coordinate the work of the various subcontractors. McInnis averred that Brasfield & Gorrie’s failure to coordinate and facilitate the work of the various subcontractors worsened as the project progressed, and Brasfield & Gorrie experienced turnover in management. This failure allegedly delayed McInnis’s work, which was not on the path toward completion, supposedly through no fault of its own. Construction issues were amplified when on March 11, 2020, Mississippi experienced its first reported case of COVID-19. On April 1, 2020, the Mississippi Governor instituted a shelter in place order in response to the ongoing pandemic, requiring certain nonessential businesses to close and recommending social distancing to reduce the spread of the coronavirus in Mississippi. The children’s hospital was not classified as an existing infrastructure as it was a nonoperational work in progress and thus was not subject to the executive order’s exception to the governmental shutdowns. By May 8, 2020, McInnis had suffered an approximately 40 percent loss in its workforce due to employees testing positive for COVID-19. Despite the decrease in the available workforce, Brasfield & Gorrie demanded McInnis perform under its contractual obligation. McInnis took measures to continue the work. Brasfield & Gorrie further declined requests for accommodation and instead terminated McInnis on May 13, 2020. The case before the Mississippi Supreme Court here stemmed from disagreements and a broken contract between the parties, contesting whether arbitration was appropriate to settle their disputes. The trial court compelled arbitration, and the Supreme Court affirmed. View "McInnis Electric Company v. Brasfield & Gorrie, LLC et al." on Justia Law

Breadeaux’s Pisa, LLC (“Breadeaux”) initiated this action against its franchisee, Beckman Bros. Ltd. (“Main Street Pizza”), in federal court seeking a preliminary injunction, a permanent injunction, and a declaratory judgment. After litigating its preliminary injunction, mediating, and participating in discovery proceedings, Breadeaux filed a demand for arbitration in which it sought to relitigate its preliminary injunction and avoid the court’s adverse discovery rulings. Breadeaux then moved to stay all proceedings pending completion of arbitration. The district court denied Breadeaux’s motion.   The Eighth Circuit affirmed. The court explained that Section 3’s stay provision is mandatory when “the issue involved in such suit or proceeding is referable to arbitration” under a valid arbitration agreement. 9 U.S.C. Section 3. The court wrote that it is unpersuaded by Breadeaux’s assertion that the only reasonable reading of the arbitration provision in the Agreement is that all claims or disputes, besides Breadeaux’s equitable claims, must be arbitrated. Additionally, Breadeaux elected to enforce the Agreement by judicial process, not through mediation and arbitration. Under these circumstances, Breadeaux’s claims are not referable. View "Breadeaux's Pisa, LLC v. Beckman Bros. Ltd." on Justia Law

At the request of Plaintiffs/cross-defendants, the trial court issued a prejudgment right to attach orders (RTAO) in the aggregate amount of $7,192,607.16 against their former employer, NMSI, Inc. Appealing the orders as authorized by Code of Civil Procedure section 904.1, subdivision (a)(5),1 NMSI contends Plaintiffs failed to establish the probable validity of their claims because, contrary to the allegations in their first amended complaint, the agreements underlying their breach of contract causes of action had been modified through an exchange of emails, as well as by the parties’ subsequent conduct. NMSI also contends the amounts to be attached were not readily ascertainable, and the court erred in considering documents incorporated by reference into the applications for a writ of attachment.   The Second Appellate District affirmed. The court held that substantial evidence supports the trial court’s finding of the probable validity of Plaintiffs’ contract claims. The court explained that substantial evidence supports the trial court’s finding that the November 3, 2020 email does not show that “both Plaintiffs personally supervised the calculations of the Brea branch profit and loss figures . . . which reflected the modified profit-sharing model, which they then sent to and confirmed with NMSI’s accounting team,” and its further finding that the email did not confirm the modified revenue sharing agreement because it “failed to include the attachment with the cover email,” so “it cannot be determined from the November 2020 email what Plaintiffs were confirming.” The court held that the trial court did not err in determining the claims were for a fixed or readily ascertainable amount. View "Park v. NMSI, Inc." on Justia Law

Seven years ago, A.D. was hired to create a PVT (“pressure volume temperature”) simulation software program. Sah was hired by A.D. to develop a PVT software program in exchange for a stake in one of A.D.’s companies, IPSS. Eight months later, a product called InPVT hit the market. Plaintiff Calsep started looking into InPVT. In Calsep’s assessment, A.D. didn’t have the technical skills or resources to develop a PVT product. Calsep filed another motion to compel, alleging that A.D. still hadn’t adequately disclosed his source code control system. Although A.D. had “produced [a] purported source code system” in April and July, Calsep claimed that these productions were “undoubtedly incomplete” and “had been manipulated.” Believing the deletions to be intentional, Calsep filed a motion for sanctions. Afterward, A.D. filed a motion for reconsideration based on newly discovered forensic images that “vindicated” him. The magistrate judge recommended denying the motion, and the district court agreed, denying the motion for reconsideration of the sanctions order. A.D. appealed.   The Fifth Circuit affirmed the district court’s decision on A.D.'s motion for reconsideration. The court explained that A.D. cannot offer any reason—other than mere forgetfulness—why he couldn’t acquire the images sooner. Further, A.D. hasn’t shown that he acted with diligence during the case to locate these images. Moreover, the court explained that although A.D. argues that the images change the game, Calsep’s expert insists that too much data is still missing from the source code control system, rendering a proper review impossible. The court noted that there was no reason to question the district court’s judgment crediting Calsep’s expert testimony. View "Calsep v. Dabral" on Justia Law

The issue this case presented for the Delaware Supreme Court's review stemmed from a failed, multibillion-dollar merger (the “Merger”) of two fuel pipeline giants - The Williams Companies, Inc. (“Williams”) and Energy Transfer LP (“ETE”). The parties spent a decade litigating over various fees to which they argued they were entitled under the Merger Agreement. ETE continued to assert its entitlement to a $1.48 billion breakup fee, despite being the party who terminated the Merger. It also disputed that it had to pay Williams a $410 million reimbursement fee, which it was required to pay if the Merger failed and certain conditions were met. Finally, ETE argued a related $85 million attorney’s fee award was unreasonable. But the Supreme Court found no error with the Court of Chancery’s opinions that held ETE was not entitled to an over-one-billion-dollar fee and find that ETE had to pay Williams the $410 million reimbursement fee and the related $85 million in attorney’s fees. View "Energy Transfer, LP v. The Williams Companies, Inc." on Justia Law