Defendant resides in Arcadia, California, and holds a Chinese resident identification card. In 2019, Defendant made several trips to Macau, which is an autonomous region on the south coast of China. Gambling is legal in Macau. While in Macau, Defendant entered into seven loan agreements with Tak Chun Gaming Promotion Company Limited (Tak Chun). Tak Chun sued Long in a California state court seeking HK$74,331,320 (that is, US$9,904,787) under causes of action for (1) breach of contract, (2) quantum meruit, and (3) common counts. Following the entry of judgment for Defendant, Tak Chun appealed.   The Second Appellate District affirmed. The court concluded that the common law rule barring resort to the California courts to collect gambling debts rests on a rationale with continued vitality—namely, a policy of discouraging the creation of those debts and the financially ruinous consequences that often flow from them, regardless of whether those debts were lawfully incurred. The court explained that where, as in this case, the lender knows that the money will be used for gambling (as Tak Chun knew because it tendered Defendant casino tokens), the common law rule applies. Lastly, California courts will entertain a lawsuit seeking an accounting following a transaction to sell a casino, but such a lawsuit does not directly involve any gamblers and hence does not hasten any gambler’s financial ruin; while such a lawsuit involves the gambling industry in general, it does not implicate the rationale underlying the common law rule. View "Tak Chun Gaming Promotion Company Limited v. Long" on Justia Law

John Doe (“Appellant”) filed this civil action alleging claims for defamation, abuse of process, tortious interference with contract, intentional infliction of emotional distress, and civil conspiracy against Jane Doe (“Appellee”) after Appellee accused Appellant of sexual assault. When Appellant filed his complaint, he also filed an ex parte motion to proceed using the pseudonym “John Doe” rather than his real name. The district court denied the motion.   The Fourth Circuit affirmed. The court explained that in considering the district court’s entire analysis of the James factors, it concluded that the district court did not abuse its discretion because it did not rely on incorrect factual or legal premises, nor did it give any indication that it was acting by general rule. Instead, the district court conducted a thorough, case-specific analysis when it exercised its discretion. The court wrote that the district court considered each of Appellant’s arguments, and it carefully balanced Appellant’s stated interests against the public’s interest in the openness of judicial proceedings as required by Public Citizen. It did not abuse its discretion in doing so. View "John Doe v. Jane Doe" on Justia Law

Plaintiff appealed from a partial final judgment of the district court dismissing his Connecticut state law claims for defamation and tortious interference with contract against Defendant, who accused Plaintiff of sexual assault in 2015 while the two were students at Yale University. Plaintiff argued that the district court erred in finding (1) Defendant to enjoy absolute quasi-judicial immunity for statements made at the 2018 Yale disciplinary hearing that resulted in Plaintiff’s expulsion from the university and (2) Plaintiff’s tortious interference claims based on Defendant’s original 2015 accusations to be untimely. On preliminary review, the Second Circuit was unable to determine whether Connecticut would recognize the Yale disciplinary hearing at issue as a quasi-judicial proceeding supporting absolute immunity in this case. Accordingly, the court certified questions pertinent to that determination to the Connecticut Supreme Court. That court responded that absolute immunity does not apply in this case because Yale’s disciplinary hearing was not a quasi-judicial proceeding in that it lacked procedural safeguards associated with judicial proceedings.   In response, The Second Circuit affirmed in part, vacated in part, and remanded. The court explained that while the Connecticut Supreme Court recognized the possibility for participants in such a hearing to be shielded by qualified immunity, the Connecticut Supreme Court concluded that Defendant is not presently entitled to dismissal on that ground because Plaintiff’s complaint sufficiently pleads the malice necessary to defeat such immunity. With this guidance as to Connecticut law, the court concluded on this appeal that Plaintiff’s complaint should not have been dismissed against Defendant except as to his tortious interference claim based on 2015 statements, which is untimely. View "Khan v. Yale Univ." on Justia Law

The Supreme Court reversed the judgment of the trial court granting the IU Credit Union's (IUCU) motion to compel individual arbitration and finding an enforceable agreement to arbitrate between the parties, holding that Tonia Land's silence and inaction did not amount to acceptance of the agreement.When Land, who maintained at least two checking accounts with IUCU, registered for online banking for one of her accounts she received by email a an agreement (the disclosure) permitting ICU to modify the terms and conditions to its services and send any notice to Land via email. Under the disclosure, Land was deemed to have received any such notice three days after it was sent. IUCU later sent Land an addendum, which Land claimed never to have received. Land later filed a class action complaint alleging breach of contract and other claims based on the agreement's amendment. IUCU moved to compel individual arbitration, which the trial court granted. The Supreme Court reversed, holding (1) IUCU provided Land with reasonable written notice of its offer to amend the agreement; (2) Land's silence and inaction did not amount to an acceptance of IUCU's offer; and (3) therefore, there was no enforceable agreement to arbitrate. View "Land v. IU Credit Union" on Justia Law

BioCorRx, Inc. (BioCorRx) was a publicly traded company primarily engaged in the business of providing addiction treatment services and related medication. It issued several press releases that allegedly made misrepresentations and improperly disclosed confidential information about a treatment it was developing for opioid overdose. VDM Biochemicals, Inc. (VDM) specializes in the synthesis and distribution of chemicals, reagents, and other specialty products for life science research. It owned a patent (the patent) for VDM-001, a compound with potential use as a treatment for opioid overdose. In September 2018, VDM and BioCorRx entered into a Mutual Nondisclosure & Confidentiality Agreement (the NDA), which restricted each party’s disclosure of confidential information as they discussed forming a business relationship. A month later, VDM and BioCorRx signed a Letter of Intent to Enter Definitive Agreement to Acquire Stake in Intellectual Property (the letter of intent). The letter of intent memorialized the parties’ shared desire whereby BioCorRx would partner with VDM to develop and commercialize VDM-001. BioCorRx and VDM never signed a formal contract concerning VDM-001. Their relationship eventually soured. BioCorRx filed a complaint (the complaint) against VDM; VDM cross-complained. In response, BioCorRx filed the anti-SLAPP motion at issue here, seeking to strike all the allegations from the cross-complaint concerning the press releases. The Court of Appeal found these statements fell within the commercial speech exemption of California's Code of Civil Procedure section 425.16 (the anti-SLAPP statute) because they were representations about BioCorRx’s business operations that were made to investors to promote its goods and services through the sale of its securities. Since these statements were not protected by the anti-SLAPP statute, the Court reversed the part of the trial court’s order granting the anti-SLAPP motion as to the press releases. The Court affirmed the unchallenged portion of the order striking unrelated allegations. View "BioCorRx, Inc. v. VDM Biochemicals, Inc." on Justia Law

Construction firm Brasfield & Gorrie, LLC, received the prime contract to expand the University of Mississippi Medical Center Children’s Hospital in 2017. Electrical contractor McInnis Electric Company secured the winning bid to install the electrical and low voltage systems package for the project and subsequently signed a subcontract with Brasfield & Gorrie. Terms of the subcontract incorporated the prime contract, which were related to the same project by reference. The contract provided that work was set to begin on the project on February 15, 2018. However, McInnis, was directed not to report on site until June 4, 2018, and, due to delays, was unable to begin until July 23, 2018. As work progressed, the schedule allegedly became delayed as a result of Brasfield & Gorrie’s failure to coordinate the work of the various subcontractors. McInnis averred that Brasfield & Gorrie’s failure to coordinate and facilitate the work of the various subcontractors worsened as the project progressed, and Brasfield & Gorrie experienced turnover in management. This failure allegedly delayed McInnis’s work, which was not on the path toward completion, supposedly through no fault of its own. Construction issues were amplified when on March 11, 2020, Mississippi experienced its first reported case of COVID-19. On April 1, 2020, the Mississippi Governor instituted a shelter in place order in response to the ongoing pandemic, requiring certain nonessential businesses to close and recommending social distancing to reduce the spread of the coronavirus in Mississippi. The children’s hospital was not classified as an existing infrastructure as it was a nonoperational work in progress and thus was not subject to the executive order’s exception to the governmental shutdowns. By May 8, 2020, McInnis had suffered an approximately 40 percent loss in its workforce due to employees testing positive for COVID-19. Despite the decrease in the available workforce, Brasfield & Gorrie demanded McInnis perform under its contractual obligation. McInnis took measures to continue the work. Brasfield & Gorrie further declined requests for accommodation and instead terminated McInnis on May 13, 2020. The case before the Mississippi Supreme Court here stemmed from disagreements and a broken contract between the parties, contesting whether arbitration was appropriate to settle their disputes. The trial court compelled arbitration, and the Supreme Court affirmed. View "McInnis Electric Company v. Brasfield & Gorrie, LLC et al." on Justia Law

The Court of Appeals answered in the negative the question of whether Insurance Law 3203(a)(2), which requires insurers to refund a portion of a life insurance premium "if the death of the insured occurs during a period for which the premium has been paid," holding that the plain language of section 3203(a)(2) does not apply to discretionary payments like those at issue in this case.In this action concerning a contract for a life insurance policy entered into between a family trust with Defendant, Plaintiff, as trustee of the trust, filed this putative class action against Defendant for breach of contract, alleging that its refusal to refund a prorated portion of the final year's planned premium violated section 3203(a)(2). The federal district court granted Defendant's motion to dismiss, concluding that section 3203(a)(2) did not require the refund. The federal court of appeals certified to the Court of Appeals a question of law. The Court of Appeals answered that section 3203(a)(2) did not apply to discretionary payments like those at issue in this case. View "Nitkewicz v. Lincoln Life & Annuity Co. of N.Y." on Justia Law

The Supreme Court reversed the judgment of the court of appeals concluding that Acuity was not required to provide coverage for the car accident in this case, holding that Acuity must provide coverage for the accident.Ashton Smith, who was insured by Acuity and had borrowed a friend's car, was involved in an accident. The car's owner was insured by Progressive Speciality Insurance Company. Under the Progressive policy, Smith was not an "insured person" when he was driving his friend's car, but he was covered by the plain language of the Acuity policy. The trial court found Acuity responsible for providing liability coverage. The court of appeals reversed. The Supreme Court reversed, holding that under the plain language of the two policies at issue, Acuity was responsible for providing coverage. View "Acuity, A Mutual Insurance Co. v. Progressive Specialty Insurance Co." on Justia Law

Kenai Ironclad Corporation (“Kenai” or “Plaintiff”) alleged that CP Marine Services, LLC, breached its contract to repair and convert Kenai’s offshore supply vessel to a salmon fishing tender for use in Alaska. After Kenai expressed dissatisfaction with the work, the relationship deteriorated. Kenai alleged that, after paying its final invoice, it attempted to remove its vessel from CP Marine’s shipyard, but as it did so, CP Marine and codefendant Ten Mile Exchange, LLC (“TME”) (collectively, “Defendants”) rammed, wrongfully seized, detained, and converted Kenai’s vessel for five days before finally releasing it the district court found that CP Marine did not breach its contract with Kenai but did wrongfully seize, detain, and convert the vessel. The district court awarded punitive damages and attorney’s fees for Defendants’ bad faith and reckless behavior in ramming, seizing, and converting the vessel for five days. Defendants appealed.   The Fifth Circuit affirmed the district court’s finding that Defendants wrongfully seized and converted Kenai’s vessel in bad faith and in a manner egregious enough to warrant an award of punitive damages. The court vacated the district court’s award of damages and remanded on the limited basis of clarifying the court’s award. The court found that Kenai presented sufficient evidence and testimony to support the district court’s finding that Defendants’ conduct was in bad faith, in callous disregard for the safety of the people aboard the vessels, and in reckless disregard of Kenai’s rights. Hence, the district court did not clearly err in finding facts sufficient to support an award of punitive damages. View "Kenai Ironclad v. CP Marine Services" on Justia Law

Plaintiff alleged that he co-created the song “All the Way Up,” but that he has not been properly credited or compensated for his contribution. He filed this action in the district court asserting claims under the Copyright Act, as well as various tort claims. Defendants maintain that Plaintiff assigned away any rights he may have had in the song, but the agreement has never been produced, and the parties disagree about its content and effect. The district court admitted a draft version of the missing agreement as a duplicate, and then granted Defendants’ motion for summary judgment without allowing Plaintiff to conduct discovery.   The Second Circuit vacated and remanded. The court held that the district court abused its discretion in finding the draft admissible as a duplicate original under Federal Rule of Evidence 1003, but properly admitted the draft as “other evidence of the content” of the original under Rule 1004. The court further held that the district court abused its discretion in denying Plaintiff’s request to conduct discovery prior to the entry of summary judgment and erred in concluding that no genuine dispute of material fact existed based on the current record. View "Elliott v. Cartagena, et al." on Justia Law