In this appeal arising from a set of commercial construction projects the Supreme Judicial Court affirmed the judgment in favor of Fortney & Weygant, Inc. (F&W) on the counterclaims filed by Lewiston DMEP IX, LLC, et al. (collectively, GBT) for liquidated damages, affirmed in part as to the prompt payment remedies allowed to F&W, and vacated the portion of the judgment awarding attorney fees and costs to F&W pursuant to the terms of the parties' contract.The trial court determined that, in addition to damages for breach of contract, F&W was entitled to remedies, including attorney fees pursuant to Maine's prompt payment statutes, that F&W was entitled to attorney fees pursuant to the terms of the parties' contract, and that GBT was estopped from seeking to enforce a contractual right to liquidated damages against F&W. The Supreme Judicial Court held that the trial court (1) did not erroneously conclude that GBT was equitably estopped from recovering liquidated damages against F&W; (2) properly awarded F&W prompt payment remedies except to the extent that the remedy failed to account for the value of GBT's liquidated damages claims that GBT withheld in good faith; and (3) erred when it concluded that the contract contemplated an award of attorney fees outside the context of arbitration. View "Fortney & Weygandt, Inc. v. Lewiston DMEP IX, LLC" on Justia Law

Modern filed suit against Turner, alleging claims arising from a subcontract outlining Modern's role in the construction of an FBI facility. The Fourth Circuit held that the district court properly applied West Virginia's law and rejected all of Modern's claims based on the plain language of the contract. In this case, the district court granted Turner summary judgment on the field verification claim, and subsequently ruled in favor of Turner on the remaining claims.The court held that Modern and Turner were two sophisticated parties that entered into a detailed contract spelling out their rights and responsibilities in the construction of the FBI facility, and the provisions of that contract directly addressed the very issues raised in this appeal. Furthermore, the provisions of the contract compelled the result reached by the district court. Accordingly, the court affirmed the judgment. View "US f/u/b of Modern Mosaic, Ltd v. Turner Construction Co." on Justia Law

The Supreme Court affirmed in part and vacated in part the judgment of the intermediate court of appeals (ICA) in this litigation concerning a dispute arising from a 1999 contract regarding the sale of approximately twenty-three acres of land in Honualua Maui, holding the the ICA erred by holding that Wailea Resort Company was clearly entitled to certain funds but otherwise did not err.The parties in this consolidated appeal were Michael Szymanski, Wailea, and ADOA-Shinwa Development and Shinwa Golf Hawai'i Company (collectively, Shinwa). Szymanski filed this application seeking a writ of certiorari raising seven questions. The Supreme Court held (1) the questions relating to the disqualification of the Honorable Rhonda I.L. Loo were without merit; (2) the ICA did not err in its application of the law of the case doctrine to the issue of whether the ICA gravely erred when it declined to review whether the Honorable Peter T. Cahill's 2015 order entering final judgment improperly dismissed with prejudice Szymanski's third-party complaint against Shinwa; and (3) the ICA erred by holding that Wailea was clearly entitled to certain funds and by affirming the circuit court's disbursal of funds. View "Title Guaranty Escrow Services, Inc. v. Wailea Resort Co., Ltd." on Justia Law

ABK, LLC owned and operated a gas station in Post Falls, Idaho where underground storage tanks were damaged due to water infiltration into the gas stored in the tanks. After the damage occurred, ABK submitted a claim to its insurer, Mid-Century Insurance Company. Mid-Century denied the claim. ABK then sued Mid-Century alleging breach of contract and bad faith. Mid-Century moved for summary judgment on both claims. The district court granted summary judgment for Mid-Century on ABK’s breach of contract claim finding ABK failed to raise a genuine dispute as to the fact the underground storage tanks were damaged by water, specifically excluded by the terms of the policy. The district court also granted summary judgment for Mid-Century on ABK’s bad faith claim finding ABK failed to establish coverage. ABK appealed the district court’s grant of summary judgment in favor of Mid-Century on both claims. Finding no reversible error, the Idaho Supreme Court affirmed. View "ABK v. Mid-Century Insurance" on Justia Law

Plaintiff Robert Barnes filed a putative class action against defendant Security Life of Denver Insurance Company (SLD) alleging that SLD, in the course of administering life insurance policies purchased by Barnes and other similarly-situated class members, breached its contractual duties and committed the tort of conversion by imposing certain administrative costs that were not authorized under the terms of the policies. Jackson National Life Insurance Company (Jackson) moved to intervene, asserting that, as a result of reinsurance agreements entered into by SLD, Jackson was actually the entity responsible for administering Barnes’s policy and numerous other policies listed within the putative class. The district court denied Jackson’s motion. After reviewing the parties’ briefs and the record on appeal, the Tenth Circuit concluded Jackson established the requirements for intervention as of right, and accordingly reversed the decision of the district court and remanded with directions to grant Jackson’s motion to intervene. View "Barnes v. Security Life of Denver" on Justia Law

William DeVos, M.D., and Donald Simmons, M.D. (collectively, "the doctors"), appealed a preliminary injunction entered in an action filed against them by The Cunningham Group, LLC, and Cunningham Pathology, LLC. The doctors separately appealed the trial court's order denying their request to increase the amount of the surety bond for the imposition of the injunction. According to the complaint, the doctors had been employed by The Cunningham Group from April 30, 2007, until August 31, 2018, when the doctors terminated their employment without prior notice. The Cunningham Group, also identified in the complaint, other pleadings, and documents in the record as "Services LLC," provided pathology and cytology services through an agreement with Cunningham Pathology. The doctors entered into employment agreements with Services LLC in 2007, in which they agreed that, if they provided Services LLC less than 12 months' notice of their termination of their employment, they would pay Services LLC an amount equal to one year's annual salary. The doctors also agreed that, for a period of two years after the termination of employment, they would not directly or indirectly solicit any of Cunningham/Services' clients or referral sources without prior consent of Cunningham/Services. Cunningham asserted that Cunningham Pathology was an express third-party beneficiary of the doctors' employment agreements with Services LLC, and asserted claims of breach of contract and breach of fiduciary duty and sought to enforce the restrictive covenants contained in the employment agreements. Cunningham also filed a motion seeking a preliminary injunction to prohibit the doctors from violating the nonsolicitation provisions of the employment agreements. The Alabama Supreme Court found that the doctors would still be required to prove their actual damages should it later be determined that they were wrongfully enjoined. "[A]t this stage the trial court should be concerned only with setting an injunction bond amount that would adequately cover the doctors' prospective costs, damages, and attorney fees if it is later determined that the doctors were wrongfully enjoined." The Supreme Court found that based on the evidence presented to the trial court, a $25,000 injunction bond was "simply inadequate to compensate two physicians for damages and attorney fees in the event it is determined that they were wrongfully enjoined from soliciting and continuing to serve Brookwood through their new pathology business." The trial court's order denying the doctors' request to increase the amount of the injunction bond was reversed, and the case remanded for the trial court to increase the injunction-bond amount. View "DeVos v. Cunningham Group, LLC" on Justia Law

In this case examining whether the former version of the Texas Citizens Participation Act (TCPA) applies to certain counterclaims alleged in a dispute over an oil and gas lease the Supreme Court affirmed in part and reversed in part the judgment of the court of appeals dismissing all the counterclaims in this case, holding that the court of appeals properly dismissed one counterclaim but erred in dismissing the remaining counterclaims.At issue was whether each counterclaim was "based on, relates to, or is in response to" the "exercise of the right of free speech" or the "exercise of the right to petition," as defined by the governing statutory text. See Tex. Civ. Prac. & Rem. Code 27.003(a). The Supreme Court held (1) certain communications to third parties about an oil and gas lease allegedly involving the exercise of free speech, on which some of the counterclaims were based, were not covered by the TCPA because they did not relate to a matter of public concern under the TCPA, and therefore, the court of appeals erred in dismissing these counterclaims; and (2) the court of appeals correctly disposed of the "right to petition" counterclaim. View "Creative Oil & Gas, LLC v. Lona Hills Ranch, LLC" on Justia Law

The Supreme Court affirmed the trial court's judgment in this action by an employer against several of its former employees and their new employer for alleged violations of the former employees' noncompetition and non-solicitation agreements, holding that the liquidated damages provisions in the employees' contracts were unenforceable and that there remained an issue of material fact precluding summary judgment as to the employer's tortious interference claims.The employer in this case brought claims against its former employees, including tortious interference with a contractual relationship and breach of contract claims. The trial court (1) granted summary judgment for the former employees on the issue of liquidated damages, finding that the liquidated damages provisions in the employees' contracts were unenforceable as a matter of law; and (2) found that there were issues of material fact regarding precluding summary judgment on the breach of contract claim. The Supreme Court affirmed, holding (1) the liquidated damages provisions were unenforceable penalties; and (2) an issue of material fact remained as to the employer's tortious interference with a contractual relationship claim. View "American Consulting, Inc. v. Hannum Wagle & Cline Engineering, Inc." on Justia Law

The Supreme Court reversed the judgment of the district court denying PointCentral, LLC's motion to dismiss third-party claims of Big Sky Vacation Rentals, Inc. (BSVR) pursuant to Mont. R. Civ. P. 12(b), holding that the district court erred in concluding that the PointCentral/BSVR arbitration agreement was invalid or otherwise unenforceable due to lack of mutuality or equitable unconscionability.BSVR and PointCentral entered into an agreement that included a broadly-worded arbitration agreement. After BSVR was sued for contract and tort claims BSVR asserted third-party claims against PointCentral for contribution and indemnification. Based on the arbitration agreement, PointCentral filed a motion for dismissal of BSVR's third-party claims. The district court denied the motion, concluding that the agreement lacked mutual consideration and was thus unenforceable as a matter of generally applicable contract law. The Supreme Court reversed, holding that the district court erred in failing to dismiss BSVR's third-party claims because the arbitration was not unenforceable due to lack of mutuality or equitable unconscionability and did not contravene the letter or underlying purpose or policy of Mont. Code Ann. 27-1-703(4)-(5). View "Big Sky Vacation Rentals, Inc. v. PointCentral, LLC" on Justia Law

In this contract dispute, the Supreme Court affirmed the judgment of the district court awarding Flathead Management Partners (FMP) $191,876 in expectancy damages, holding that the district court did not err when it denied Gary Jystad's motion for judgment on the pleadings and when it concluded that the contract at issue was enforceable.After a fire destroyed Jystad's home he entered into a contract with FMP to restore the property and to oversee the reconstruction of the main residence. After the parties worked together for a few months, Jystad informed FMP that the contract was void because it did not contain the statutorily required disclosures for a general contractor constructing a new residence. FMP filed this action claiming expectancy damages for the full contract price. The district court granted judgment for FMP, holding that FMP was not a general contractor and that the contract was not for the construction of a new residence. The Supreme Court affirmed, holding (1) the district court did not err when it determined that the contract was not for the construction of a new residence and that FMP was not a general contractor; and (2) the court did not abuse its discretion in the award of damages. View "Flathead Management Partners, LLC v. Jystad" on Justia Law